Search

Table 4.7

Rate Schedule for Diesel Fuel Surcharge

$3.501 - $3.750 per gallon $23.00 per load
33.751 - $4.000 per gallon $30.00 per load
$4.001 - $4.250 per gallon $38.00 per load
$4.251 - $4.500 per gallon $45.00 per load
$4.501 - $4.750 per gallon $53.00 per load
$4.751 - $5.000 per gallon $60.00 per load

4.8 The fees in Sections 4.1 and 4.2 shall be increased by 3% annually on July 1°, starting July 1, 2020.

The Contract Sum shall include all items and services necessary for the proper execution and completion of
the Work.

Unless Independent Contractor has received a written exemption from the City of Nashua, Independent
Contractor shall submit an itemized Application for Payment for operations completed in accordance with
the values stated in the Agreement. Such applications shall be supported by such data substantiating the
Independent Contractor’s right to payment as the City of Nashua may reasonably require. Independent
Contractor shall submit monthly requests for payment for services performed under this agreement directly
to:

>» Electronically via email to VendorAPInvoices(@NashuaNH.gov
OR
» Paper Copies via US Mail to:
City of Nashua, City Hall
Accounts Payable

229 Main Street
Nashua, NH 03060

Please_do not submit invoices both electronically and paper copy.

In addition, and to facilitate the proper and timely payment of applications, the City of Nashua requires that
all submitted invoices contain a valid PURCHASE ORDER NUMBER.

Applications for Payment shall be submitted no later than fifteen (15) days after the end of each month. The
City of Nashua will pay for work satisfactorily completed and accurately invoiced by Independent

Contractor within thirty (30) days from the time of approval by the City of Nashua.

5, EFFECTIVE DATE OF CONTRACT. This contract shall not become effective until and unless approved by
the City of Nashua.

AG 4 of 5

6. NOTICES. All notices, requests, or approvals required or permitted to be given under this contract shall
be in writing, shall be sent by hand delivery, overnight carrier, or by United States mail, postage prepaid,
and registered or certified, and shall be addressed to:

CITY OF NASHUA REPRESENTATIVE: REPRESENTATIVE:

David Boucher, Superintendent Shelagn Conneily, Pres. RMI
Nashua Wastewater Treatment Facility 1171 NH Route 175

2 Sawmill Road Holderness, NH 03245

Nashua, NH 03060

Any notice required or permitted under this contract, if sent by United States mail, shall be deemed to be
given to and received by the addressee thereof on the third business day after being deposited in the mail.
The City of Nashua or Independent Contractor may change the address or representative by giving written
notice to the other party.

IN WITNESS WHEREOF, the parties hereto have caused this contract to be signed and intend to be legally
bound thereby.

City of Nashua, NH (signature) Resource Management, Inc. (signature)

James Donchess, Mayer
(Printed Name and Title) (Printed Name and Title)

Date Date

AG5o0f5

Vhb

Because the scope of this effort is unknown, for budgeting purposes, we assume up to 62 hours
will be required to complete the post-application coordination. If required due to an agency
request not anticipated, reallocation or an adjustment to the original Scope of Services and fee
may be necessary if the follow-up services are more than the initial allocation.

Task 12. Archaeological Survey and Coordination (Optional)

Early coordination with NHDHR suggests that archaeological field surveys are likely not
necessary. However, recognizing that some historical archaeological deposits may be affected,
under this task we propose to carry an allowance of $5,000 for an archaeological subconsultant

if the NHDHR response to the RPR requests any such work.

Task 13. Soil & Groundwater Desktop Study

VHB will conduct a review of the searchable online environmental database ("OneStop’)
maintained by the NHDES, to identify contaminant sources with the potential to significantly
impact the project. The database will be queried to select State-regulated sites located within
1,000 feet of the estimated project limits of disturbance (i.e, study area). For these sites,
pertinent information/data available in the database will be reviewed to identify those sites with
the potential to create contaminated environmental media (soil, groundwater} within the project
limits of disturbance. VHB will prepare a brief technical memorandum to summarize the findings
of this desktop study, including a supporting figure and summary table to identify: the study
area; NHDES sites identified within the study area; and, the sites that, in VHB’s opinion, have the
potential to impact the project. The memorandum will also include recommendations for further
investigation and/or construction management planning, as appropriate. VHB’s opinions of
potential project impact are not certainties as we expect they will be based on observations

made by others from widely spaced exploration and testing.

Follow-up exploration and testing may be recommended based on the OneStop database
review. Given that the necessity and scope of potential testing is unknown at this time, the costs
for additional investigation (e.g., confirmatory pre-construction soil or groundwater sampling
within the project area}, should it be recommended, are not included in this proposal. We
understand that any such required environmental sampling may become the responsibility of
the construction manager, although VHB can assist with or conduct those investigations upon

amendment of this scope.

Task 14. Soil & Groundwater Management Planning

Building on the findings from the Soil and Groundwater Desktop Study, and in consideration of
project requirements, VHB will prepare a Soil and Groundwater Management Plan (SGMP) for
use during construction. The purpose of the SGMP will be to provide guidance to the Contractor

an Ae BN

ad

10.
11.
12.
13.
14.
15.
16.
17.
18.
19.
20.
21.
22.
23.
24.
25.
26.
27.
28.
29.
30.
31.

EXHIBIT A
TABLE OF CONTENTS
GENERAL CONDITIONS

DEFINITIONS

INDEPENDENT CONTRACTOR STATUS
STANDARD OF CARE

CITY OF NASHUA REPRESENTATIVE
CHANGES TO SCOPE OF WORK

CITY OF NASHUA COOPERATION

DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR
DISCREPANCIES

TERMINATION OF CONTRACT

DISPUTE RESOLUTION

NO DAMAGES FOR DELAY

INSURANCE

INDEMNIFICATION

FISCAL CONTINGENCY

COMPENSATION

COMPLIANCE WITH APPLICABLE LAWS
NONDISCRIMINATION

ENDORSEMENT

ASSIGNMENTS, TRANSFER, DELEGATION, OR SUBCONTRACTING
City INSPECTION OF CONTRACT MATERIALS
DISPOSITION OF CONTRACT MATERIALS

PUBLIC RECORDS LAW, COPYRIGHTS, AND PATENTS
FINAL ACCEPTANCE

TAXES

NON-WAIVER OF TERMS AND CONDITIONS

RIGHTS AND REMEDIES

PROHIBITED INTERESTS

THIRD PARTY INTERESTS AND LIABILITIES
SURVIVAL OF RIGHTS AND OBLIGATIONS
SEVERABILITY

MODIFICATION OF CONTRACT AND ENTIRE AGREEMENT

CHOICE OF LAW AND VENUE

GC 1 of 11

GC--2
GC--2
GC--2
GC--3
GC--3
GC--3

GC--3
GC--4
GC--5
GC--6
GC--6
GC--7
GC--7
GC--7
GC--7
GC--8
GC--8
GC--8
GC--9
GC--9
GC--9
GC--10
GC--10
GC--10
GC--10
GC--10
GC--11
GC--1]1
GC--11
GC--1]
GC--11

General Terms and Conditions

DEFINITIONS Unless otherwise required by the context, "Independent Contractor”, and its
successors, transferees and assignees (together “Independent Contractor”) includes any of the
Independent Contractor's consultants, sub consultants, contractors, and subcontractors

INDEPENDENT CONTRACTOR STATUS The parties agree that Independent Contractor shall have
the status of and shall perform all work under this contract as an Independent Contractor,
maintaining control over all its consultants, sub consultants, contractors, or subcontractors. The
only contractual relationship created by this contract is between the City of Nashua and
Independent Contractor, and nothing in this contract shall create any contractual relationship
between the City of Nashua and Independent Contractor's consultants, sub consultants,
contractors, or subcontractors. The parties also agree that Independent Contractor is not a City of
Nashua employee and that there shall be no:

(1) Withholding of income taxes by the City of Nashua:

(2) Industrial insurance coverage provided by the City of Nashua;

(3) Participation in group insurance plans which may be available to employees of
the City of Nashua;

(4) Participation or contributions by either the Independent Contractor or the City of
Nashua to the public employee’s retirement system;

(5) Accumulation of vacation leave or sick leave provided by the City of Nashua;

(6) Unemployment compensation coverage provided by the City of Nashua.

STANDARD OF CARE Independent Contractor shall be responsible for the professional quality,
technical accuracy, timely completion, and coordination of all work performed under this
contract. Independent Contractor warrants that all work shall be performed with the degree of
professional skill, care, diligence, and sound practices and judgment that are normally exercised
by recognized professional firms with respect to services of a similar nature. It shall be the duty
of Independent Contractor to assure at its own expense that all work is technically sound and in
conformance with all applicable federal, state, and local laws, statutes, regulations, ordinances,
orders, or other requirements. In addition to all other rights which the City of Nashua may have,
Independent Contractor shall, at its own expense and without additional compensation, re-
perform work to correct or revise any deficiencies, omissions, or errors in the work or the product
of the work or which result from Independent Contractor's failure to perform in accordance with
this standard of care. Any approval by the City of Nashua of any products or services furnished
or used by Independent Contractor shall not in any way relieve Independent Contractor of the
responsibility for professional and technical accuracy and adequacy of its work. City of Nashua
review, approval, or acceptance of, or payment for any of Independent Contractor's work under
this contract shall not operate as a waiver of any of the City of Nashua's rights or causes of action
under this contract, and Independent Contractor shall be and remain liable in accordance with the
terms of the contract and applicable law.

Independent Contractor shall furnish competent and skilled personnel to perform the work under
this contract. The City of Nashua reserves the right to approve key personnel assigned by
Independent Contractor to perform work under this contract. Approved key personnel shall not
be taken off of the project by Independent Contractor without the prior written approval of the
City of Nashua, except in the event of termination of employment. Independent Contractor shall,
if requested to do so by the City of Nashua, remove from the job any personnel whom the City of
Nashua determines to be incompetent, dishonest, or uncooperative.

GC 2 of 11

4. CITY OF NASHUA REPRESENTATIVE The City of Nashua may designate a City of Nashua
representative for this contract. If designated, all notices, project materials, requests by
Independent Contractor, and any other communication about the contract shall be addressed or be
delivered to the City of Nashua Representative.

5. CHANGES TO SCOPE OF WORK The City of Nashua may, at any time, by written order, make
changes to the general scope, character, or cost of this contract and in the services or work to be
performed, either increasing or decreasing the scope, character, or cost of Independent
Contractor's performance under the contract. Independent Contractor shall provide to the City of
Nashua within 10 calendar days, a written proposal for accomplishing the change. The proposal
for a change shall provide enough detail, including personnel hours for each sub-task and cost
breakdowns of tasks, for the City of Nashua to be able to adequately analyze the proposal. The
City of Nashua will then determine in writing if Independent Contractor should proceed with any
or all of the proposed change. If the change causes an increase or a decrease in Independent
Contractor's cost or time required for performance of the contract as a whole, an equitable
adjustment shall be made and the contract accordingly modified in writing. Any claim of
Independent Contractor for adjustment under this clause shall be asserted in writing within 30
days of the date the City of Nashua notified Independent Contractor of the change.

When Independent Contractor seeks changes, Independent Contractor shall, before any work
commences, estimate their effect on the cost of the contract and on its schedule and notify the
City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail,
including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua
to be able to adequately analyze the proposal. The City of Nashua will then determine in writing
if Independent Contractor should proceed with any or all of the proposed change.

Except as provided in this paragraph, Independent Contractor shall implement no change unless
the City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the
provisions of this contract shall apply to all changes. The City of Nashua may provide verbal
approval of a change when the City of Nashua, in its sole discretion, determines that time is
critical or public health and safety are of concern. Any verbal approval shall be confirmed in
writing as soon as practicable. Any change undertaken without prior City of Nashua approval
shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract
termination.

6. CITY OF NASHUA COOPERATION The City of Nashua agrees that its personnel will cooperate
with Independent Contractor in the performance of its work under this contract and that such
personnel will be available to Independent Contractor for consultation at reasonable times and
after being given sufficient advance notice that will prevent conflict with their other
responsibilities. The City of Nashua also agrees to provide Independent Contractor with access to
City of Nashua records in a reasonable time and manner and to schedule items that require action
by the Board of Public Works and Finance Committee in a timely manner. The City of Nashua
and Independent Contractor also agree to attend all meetings called by the City of Nashua or
Independent Contractor to discuss the work under the Contract, and that Independent Contractor
may elect to conduct and record such meetings and shall later distribute prepared minutes of the
meeting to the City of Nashua.

7. DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR DISCREPANCIES
Independent Contractor warrants that it has examined all contract documents, has brought all
conflicts, errors, discrepancies, and ambiguities to the attention of the City of Nashua in writing,
and has concluded that the City of Nashua's resolution of each matter is satisfactory to
Independent Contractor. All future questions Independent Contractor may have concerning
interpretation or clarification of this contract shall be submitted in writing to the City of Nashua
within 10 calendar days of their arising. The writing shall state clearly and in full detail the basis
for Independent Contractor's question or position. The City of Nashua representative shall render

GC 3 of 11

a decision within 15 calendar days. The City of Nashua's decision on the matter is final. Any
work affected by a conflict, error, omission, or discrepancy which has been performed by
Independent Contractor prior to having received the City of Nashua's resolution shall be at
Independent Contractor's risk and expense. At all times, Independent Contractor shall carry on
the work under this contract and maintain and complete work in accordance with the
requirements of the contract or determination of the City of Nashua. Independent Contractor is
responsible for requesting clarification or interpretation and is solely liable for any cost or
expense arising from its failure to do so.

TERMINATION OF CONTRACT

A. TERMINATION, ABANDONMENT, OR SUSPENSION AT WILL. The City of Nashua, in its sole
discretion, shall have the right to terminate, abandon, or suspend all or part of the project and
contract at will. If the City of Nashua chooses to terminate, abandon, or suspend all or part of the
project, it shall provide Independent Contractor 10 day’s written notice of its intent to do so.

If all or part of the project is suspended for more than 90 days, the suspension shall be treated as a
termination at will of all or part of the project and contract.

Upon receipt of notice of termination, abandonment, or suspension at will, Independent
Contractor shall:

—_

Immediately discontinue work on the date and to the extent specified in the notice.

2. Place no further orders or subcontracts for materials, services, or facilities, other than as
may be necessary or required for completion of such portion of work under the contract
that is not terminated.

3. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or subcontracts to the extent they relate
to the performance of work terminated, abandoned, or suspended under the notice,
assign to the City of Nashua any orders or subcontracts specified in the notice, and
revoke agreements specified in the notice.

4. Not resume work after the effective date of a notice of suspension until receipt of a

written notice from the City of Nashua to resume performance.

In the event of a termination, abandonment, or suspension at will, Independent Contractor shall
receive all amounts due and not previously paid to Independent Contractor for work satisfactorily
completed in accordance with the contract prior to the date of the notice and compensation for
work thereafter completed as specified in the notice. No amount shall be allowed or paid for
anticipated profit on unperformed services or other unperformed work.

B. TERMINATION FOR CAUSE This agreement may be terminated by the City of Nashua on 10
calendar day’s written notice to Independent Contractor in the event of a failure by Independent
Contractor to adhere to any or all the terms and conditions of the contract or for failure to
satisfactorily, in the sole opinion of the City of Nashua, to complete or make sufficient progress
on the work in a timely and professional manner. Independent Contractor shall be given an
opportunity for consultation with the City of Nashua prior to the effective date of the termination.
Independent Contractor may terminate the contract on 10 calendar days written notice if, through
no fault of Independent Contractor, the City of Nashua fails to pay Independent Contractor for 45
days after the date of approval by the City of Nashua of any Application for Payment.

Upon receipt of notice of termination for cause, Independent Contractor shall:
1. Immediately discontinue work on the date and to the extent specified in the notice.

2. Provide the City of Nashua with a list of all unperformed services.

GC 4 of 11

3. Place no further orders or sub-contracts for materials, services, or facilities, other than
as may be necessary or required for completion of such portion of work under the
contract that is not terminated.

4. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or sub contracts to the extent they relate
to the performance of work terminated, abandoned, or suspended under the notice,
assign to the City of Nashua any orders or sub contracts specified in the notice, and
revoke agreements specified in the notice.

5. Not resume work after the effective date of a notice of termination unless and until
receipt of a written notice from the City of Nashua to resume performance.

In the event of a termination for cause, Independent Contractor shall receive all amounts due and
not previously paid to Independent Contractor for work satisfactorily completed in accordance
with the contract prior to the date of the notice, less all previous payments. No amount shall be
allowed or paid for anticipated profit on unperformed services or other unperformed work. Any
such payment may be adjusted to the extent of any additional costs occasioned to the City of
Nashua by reasons of Independent Contractor's failure. Independent Contractor shall not be
relieved of liability to the City of Nashua for damages sustained from the failure, and the City of
Nashua may withhold any payment to the Independent Contractor until such time as the exact
amount of damages due to the City of Nashua is determined. All claims for payment by the
Independent Contractor must be submitted to the City of Nashua within 30 days of the effective
date of the notice of termination.

If after termination for the failure of Independent Contractor to adhere to any of the terms and
conditions of the contract or for failure to satisfactorily, in the sole opinion of the City of Nashua,
to complete or make sufficient progress on the work in a timely and professional manner, it is
determined that Independent Contractor had not so failed, the termination shall be deemed to
have been a termination at will. In that event, the City of Nashua shall, if necessary, make an
adjustment in the compensation paid to Independent Contractor such that Independent Contractor
receives total compensation in the same amount as it would have received in the event of a
termination-at-will.

C. GENERAL PROVISIONS FOR TERMINATION Upon termination of the contract, the City of
Nashua may take over the work and prosecute it to completion by agreement with another party
or otherwise. In the event Independent Contractor shall cease conducting business, the City of
Nashua shall have the right to solicit applications for employment from any employee of the
Independent Contractor assigned to the performance of the contract.

Neither party shall be considered in default of the performance of its obligations hereunder to the
extent that performance of such obligations is prevented or delayed by any cause, existing or
future, which is beyond the reasonable control of such party. Delays arising from the actions or
inactions of one or more of Independent Contractor's principals, officers, employees, agents,
subcontractors, consultants, vendors, or suppliers are expressly recognized to be within
Independent Contractor's control.

DISPUTE RESOLUTION The parties shall attempt to resolve any dispute related to this contract
as follows. Either party shall provide to the other party, in writing and with full documentation to
verify and substantiate its decision, its stated position concerning the dispute. No dispute shall be
considered submitted and no dispute shall be valid under this provision unless and until the
submitting party has delivered the written statement of its position and full documentation to the
other party. The parties shall then attempt to resolve the dispute through good faith efforts and
negotiation between the City of Nashua Representative and a Independent Contractor
Representative. At all times, Independent Contractor shall carry on the work under this contract
and maintain and complete work in accordance with the requirements of the contract or
determination or direction of the City of Nashua. If the parties are unable to resolve their dispute

GC 5 of 11

lu.

11.

as described above within 30 days, the parties may request that the dispute be submitted to the
Board of Public Works for resolution. If the parties are dissatisfied with the decision of the Board
of Public Works, the parties’ reserve the right to pursue any available legal and/or equitable
remedies for any breaches of this contract except as that right may be limited by the terms of this
contract.

NO DAMAGES FOR DELAY Apart from a written extension of time, no payment, compensation,
or adjustment of any kind shall be made to Independent Contractor for damages because of
hindrances or delays in the progress of the work from any cause, and Independent Contractor
agrees to accept in full satisfaction of such hindrances and delays any extension of time that the
City of Nashua may provide.

INSURANCE Independent Contractor shall carry and maintain in effect during the performance of
services under this contract:

> General Liability insurance in the amount of $1,000,000 per occurrence; $2,000,000
aggregate;

> $1,000,000 Combined Single Limit Automobile Liability; Coverage must include all
owned, non-owned and hired vehicles ; and

>» Workers' Compensation Coverage in compliance with the State of New Hampshire
statutes, $100,000/$500,000/$ 100,000.

Independent Contractor shall maintain in effect at all times during the performance under this
contract all specified insurance coverage with insurers. None of the requirements as to types
and limits to be maintained by Independent Contractor are intended to and shall not in any
manner limit or qualify the liabilities and obligations assumed by Independent Contractor under
this contract. The City of Nashua shall not maintain any insurance on behalf of Independent
Contractor. Subcontractors are subject to the same insurance requirements as Independent
Contractor and it shall be the Independent Contractor’s responsibility to ensure compliance of
this requirement.

Independent Contractor will provide the City of Nashua with certificates of insurance for
coverage as listed below and endorsements affecting coverage required by the contract. The
City of Nashua requires thirty days written notice of cancellation or material change in
coverage. The certificates and endorsements for each insurance policy must be signed by a
person authorized by the insurer and who is licensed by the State of New Hampshire. General
Liability and Auto Liability policies must name the City of Nashua as an additional
insured and reflect on the certificate of insurance. Independent Contractor is responsible for
filing updated certificates of insurance with the City of Nashua's Risk Management Department
during the life of the contract.

>» All deductibles and self-insured retentions shall be fully disclosed in the certificate(s) of
insurance.

>» The specified insurance requirements do not relieve Independent Contractor of its
responsibilities or limit the amount of its liability to the City of Nashua or other persons,
and Independent Contractor is encouraged to purchase such additional insurance, as it
deems necessary.

> The insurance provided herein is primary, and no insurance held or owned by the City of
Nashua shall be called upon to contribute to a loss.

GC 6 of 11

12.

13.

14.

15.

> Independent Contractor is responsible for and required to remedy all damage or loss to
any property, including property of the City of Nashua, caused in whole or part by
Independent Contractor or anyone employed, directed, or supervised by Independent
Contractor.

> The insurance provided herein is primary, and no insurance held or owned by the City
of Nashua shall be called upon to contribute to a loss.

»® — Independent Contractor is responsible for and required to remedy all damage or loss to
any property, including property of the City of Nashua, caused in whole or part by
Independent Contractor or anyone employed, directed, or supervised by Independent
Contractor

INDEMNIFICATION Regardless of any coverage provided by any insurance, Independent
Contractor agrees to indemnify and hold harmless the City of Nashua, its agents, officials,
employees and authorized representatives and their employees from and against any and all suits,
causes of action, legal or administrative proceedings, arbitrations, claims, demands, damages,
liabilities, interest, attorney’s fees, costs and expenses of any kind or nature in any manner
caused, occasioned, or contributed to in whole or in part by reason of any negligent act, omission,
or fault or willful misconduct, whether active or passive, of Independent Contractor or of anyone
acting under its direction or control or on its behalf in connection with or incidental to the
performance of this contract. Independent Contractor’s indemnity and hold harmless obligations,
or portions thereof, shall not apply to liability caused by the sole negligence or willful misconduct
of the party indemnified or held harmless.

FISCAL CONTINGENCY All payments under this contract are contingent upon the availability to
the City of Nashua of the necessary funds. This contract shall terminate and the City of Nashua's
obligations under it shall be extinguished at the end of any fiscal year in which the City of Nashua
fails to appropriate monies for the ensuing fiscal year sufficient for the performance of this
contract.

Nothing in this contract shall be construed to provide Independent Contractor with a right of
payment over any other entity. Any funds obligated by the City of Nashua under this contract
that are not paid to Independent Contractor shall automatically revert to the City of Nashua’s
discretionary control upon the completion, termination, or cancellation of the agreement. The
City of Nashua shall not have any obligation to re-award or to provide, in any manner, the
unexpended funds to Independent Contractor. Independent Contractor shall have no claim of any
sort to the unexpended funds.

COMPENSATION Review by the City of Nashua of Independent Contractor's submitted monthly
invoice forms and progress reports for payment will be promptly accomplished by the City of
Nashua. If there is insufficient information, the City of Nashua may require Independent
Contractor to submit additional information. Unless the City of Nashua, in its sole discretion,
decides otherwise, the City of Nashua shall pay Independent Contractor in full within 30 days of
approval of the submitted monthly invoice forms and progress reports.

COMPLIANCE WITH APPLICABLE LAWS Independent Contractor, at all times, shall fully and
completely comply with all applicable local, state and federal laws, statutes, regulations,
ordinances, orders, or requirements of any sort in carrying out the obligations of this contract,
including, but not limited to, all federal, state, and local accounting procedures and requirements,
all immigration and naturalization laws, and the Americans With Disabilities Act. Independent
Contractor shall, throughout the period services are to be performed under this contract, monitor
for any changes to the applicable laws, statutes, regulations, ordinances, orders, or requirements,
shall promptly notify the City of Nashua in writing of any changes to the same relating to or
affecting this contract, and shall submit detailed documentation of any effect of the change in
terms of both time and cost of performing the contract.

GC 7 of 11