Search

2. WORK TO BE PERFORMED Except as otherwise provided in this contract, Independent Contractor shall
furnish all services, equipment, and materials and shall perform all operations necessary and required to
carry out and perform in accordance with the terms and conditions of the contract the work described.

DESCRIPTION OF WORK:

Independent Contractor shall be responsible for a one-time grinding operation, date of service to be
negotiated. Independent Contractor is expected to grind all of the brush located in both piles and to
provide all of the necessary equipment and personnel to accomplish the work without any assistance
from the Four Hills Landfill staff or equipment. Independent Contractor may remove or leave of any
processed wood chips from grinding operations.

3. PERIOD OF PERFORMANCE. Independent Contractor shall perform and complete all work by

June 30, 2021 which date shall only be altered by mutually approved written agreement to extend the period
of performance or by termination in accordance with the terms of the contract. Independent Contractor shall
begin performance upon receipt of an Executed Contract and a valid Purchase Order issued from the City of
Nashua.

4. COMPENSATION. Independent Contractor agrees to perform the work for a total cost not to exceed

FIFTY-FOUR THOUSAND FOUR HUNDRED EIGHTY and 00/100 DOLLARS
($54,480.00)

The Contract Sum shall include all items and services necessary for the proper execution and completion
of the Work.

Unless Independent Contractor has received a written exemption from the City of Nashua, Independent
Contractor shall submit an itemized Application for Payment for operations completed in accordance with
the values stated in the Agreement. Such applications shall be supported by such data substantiating the
Independent Contractor’s right to payment as the City of Nashua may reasonably require. Independent
Contractor shall submit requests for payment for services performed under this agreement directly to:

>» Electronically via email to VendorAPInvoices@NashuaNH. gov
OR

>» Paper Copies via US Mail to:

City of Nashua, City Hall
Accounts Payable

229 Main Street

Nashua, NH 03060

Please_do not submit invoices both electronically and paper copy.

In addition, and to facilitate the proper and timely payment of applications, the City of Nashua requires
that all submitted invoices contain a valid PURCHASE ORDER NUMBER.

AG 2 of 3

The City of Nashua will pay for work satisfactorily completed and accurately invoiced by Independent
Contractor within thirty (30) days from the time of approval by the City of Nashua.

5. EFFECTIVE DATE OF CONTRACT. This contract shall not become effective until the date of execution by
the City of Nashua.

6. NoTicés. All notices, requests, or approvals required or permitted to be given under this contract shall
be in writing, shall be sent by hand delivery, overnight carrier, or by United States mail, postage prepaid,
and registered or certified, and shall be addressed to;

Any notice required or permitted under this contract, if sent by United States mail, shall be deemed to be
given to and received by the addressee thereof on the third business day after being deposited in the mail.

The City of Nashua or Independent Contractor may change the address or representative by giving written
notice to the other party.

IN WITNESS WHEREOF, the parties hereto have caused this contract to be signed and intend tw be legally
bound thereby.

Set ei

City of Nashua, NH (signature) Site One Landstape Supply dba The Dirt Doctors

James W_Donchess, Maver Berths Fines Ste = " - nag Ka
e ard Title

(Printed Name and Title) (Printed Nam

Date Date

AG 3 of3

Sa nM FY N

~

10.
11.
12.
13.
14.
15.
16.
17.
18.
19.
20.
21.
22.
23.
24.
25.
26.
27.
28.
29.
30.
31,

EXHIBIT A
TABLE OF CONTENTS
GENERAL CONDITIONS

DEFINITIONS

INDEPENDENT CONTRACTOR STATUS
STANDARD OF CARE

CITY OF NASHUA REPRESENTATIVE
CHANGES TO SCOPE OF WORK

CITY OF NASHUA COOPERATION

DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR
DISCREPANCIES

TERMINATION OF CONTRACT

DISPUTE RESOLUTION

NO DAMAGES FOR DELAY

INSURANCE

INDEMNIFICATION

FISCAL CONTINGENCY

COMPENSATION

COMPLIANCE WITH APPLICABLE LAWS
NONDISCRIMINATION

ENDORSEMENT

ASSIGNMENTS, TRANSFER, DELEGATION, OR SUBCONTRACTING
Ciry INSPECTION OF CONTRACT MATERIALS
DISPOSITION OF CONTRACT MATERIALS

PUBLIC RECORDS LAW, COPYRIGHTS, AND PATENTS
FINAL ACCEPTANCE

TAXES

NON-WAIVER OF TERMS AND CONDITIONS

RIGHTS AND REMEDIES

PROHIBITED INTERESTS

THIRD PARTY INTERESTS AND LIABILITIES
SURVIVAL OF RIGHTS AND OBLIGATIONS
SEVERABILITY

MODIFICATION OF CONTRACT AND ENTIRE AGREEMENT

CHOICE OF LAW AND VENUE

GC 1 of 13

1.

General Terms and Conditions

DEFINITIONS Unless otherwise required by the context, "Independent Contractor’, and its
successors, transferees and assignees (together “Independent Contractor”) includes any of
the Independent Contractor's consultants, sub consultants, contractors, and subcontractors

INDEPENDENT CONTRACTOR STATUS The parties agree that Independent Contractor shall
have the status of and shall perform all work under this contract as an Independent
Contractor, maintaining control over all its consultants, sub consultants, contractors, or
subcontractors. The only contractual relationship created by this contract is between the
City of Nashua and Independent Contractor, and nothing in this contract shall create any
contractual relationship between the City of Nashua and Independent Contractor's
consultants, sub consultants, contractors, or subcontractors. The parties also agree that
Independent Contractor is not a City of Nashua employee and that there shall be no:

(1) Withholding of income taxes by the City of Nashua:

(2) Industrial insurance coverage provided by the City of Nashua;

(3) Participation in group insurance plans which may be available to employees
of the City of Nashua;

(4) Participation or contributions by either the Independent Contractor or the
City of Nashua to the public employee’s retirement system;

(5) Accumulation of vacation leave or sick leave provided by the City of
Nashua;

(6) Unemployment compensation coverage provided by the City of Nashua.

STANDARD OF CARE Independent Contractor shall be responsible for the professional
quality, technical accuracy, timely completion, and coordination of all work performed
under this contract. Independent Contractor warrants that all work shall be performed with
the degree of professional skill, care, diligence, and sound practices and judgment that are
normally exercised by recognized professional firms with respect to services of a similar
nature. It shall be the duty of Independent Contractor to assure at its own expense that all
work is technically sound and in conformance with all applicable federal, state, and local
laws, statutes, regulations, ordinances, orders, or other requirements. In addition to all
other rights which the City of Nashua may have, Independent Contractor shall, at its own
expense and without additional compensation, re-perform work to correct or revise any
deficiencies, omissions, or errors in the work or the product of the work or which result
from Independent Contractor's failure to perform in accordance with this standard of care.
Any approval by the City of Nashua of any products or services furnished or used by
Independent Contractor shall not in any way relieve Independent Contractor of the
responsibility for professional and technical accuracy and adequacy of its work. City of
Nashua review, approval, or acceptance of, or payment for any of Independent Contractor's
work under this contract shall not operate as a waiver of any of the City of Nashua's rights
or causes of action under this contract, and Independent Contractor shall be and remain
liable in accordance with the terms of the contract and applicable law.

Independent Contractor shall furnish competent and skilled personnel to perform the work
under this contract. The City of Nashua reserves the right to approve key personnel
assigned by Independent Contractor to perform work under this contract. Approved key
personnel shall not be taken off of the project by Independent Contractor without the prior

GC 2 of 13

written approval of the City of Nashua, except in the event of termination of employment.
Independent Contractor shall, if requested to do so by the City of Nashua, remove from the
job any personnel whom the City of Nashua determines to be incompetent, dishonest, or
uncooperative.

CITY OF NASHUA REPRESENTATIVE The City of Nashua may designate a City of Nashua
representative for this contract. If designated, all notices, project materials, requests by
Independent Contractor, and any other communication about the contract shall be
addressed or be delivered to the City of Nashua Representative.

CHANGES TO SCOPE OF WORK The City of Nashua may, at any time, by written order,
make changes to the general scope, character, or cost of this contract and in the services or
work to be performed, either increasing or decreasing the scope, character, or cost of
Independent Contractor's performance under the contract. Independent Contractor shall
provide to the City of Nashua within 10 calendar days, a written proposal for accomplishing
the change. The proposal for a change shall provide enough detail, including personnel
hours for each sub-task and cost breakdowns of tasks, for the City of Nashua to be able to
adequately analyze the proposal. The City of Nashua will then determine in writing if
Independent Contractor should proceed with any or all of the proposed change. If the
change causes an increase or a decrease in Independent Contractor's cost or time required
for performance of the contract as a whole, an equitable adjustment shall be made and the
contract accordingly modified in writing. Any claim of Independent Contractor for
adjustment under this clause shall be asserted in writing within 30 days of the date the City
of Nashua notified Independent Contractor of the change.

When Independent Contractor seeks changes, Independent Contractor shall, before any
work commences, estimate their effect on the cost of the contract and on its schedule and
notify the City of Nashua in writing of the estimate. The proposal for a change shall
provide enough detail, including personnel hours for each sub-task and cost breakdowns
of tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of
Nashua will then determine in writing if Independent Contractor should proceed with any
or all of the proposed change.

Except as provided in this paragraph, Independent Contractor shall implement no change
unless the City of Nashua in writing approves the change. Unless otherwise agreed to in
writing, the provisions of this contract shall apply to all changes. The City of Nashua may
provide verbal approval of a change when the City of Nashua, in its sole discretion,
determines that time is critical or public health and safety are of concern. Any verbal
approval shall be confirmed in writing as soon as practicable. Any change undertaken
without prior City of Nashua approval shall not be compensated and is, at the City of
Nashua's election, sufficient reason for contract termination.

CITY OF NASHUA COOPERATION The City of Nashua agrees that its personnel will
cooperate with Independent Contractor in the performance of its work under this contract
and that such personnel will be available to Independent Contractor for consultation at
reasonable times and after being given sufficient advance notice that will prevent conflict
with their other responsibilities. The City of Nashua also agrees to provide Independent
Contractor with access to City of Nashua records in a reasonable time and manner and to
schedule items that require action by the Board of Public Works and Finance Committee
in a timely manner. The City of Nashua and Independent Contractor also agree to attend
all meetings called by the City of Nashua or Independent Contractor to discuss the work

GC 3 of 13

under the Contract, and that Independent Contractor may elect to conduct and record such
meetings and shall later distribute prepared minutes of the meeting to the City of Nashua.

DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR DISCREPANCIES
Independent Contractor warrants that it has examined all contract documents, has brought
all conflicts, errors, discrepancies, and ambiguities to the attention of the City of Nashua
in writing, and has concluded that the City of Nashua's resolution of each matter is
satisfactory to Independent Contractor. All future questions Independent Contractor may
have concerning interpretation or clarification of this contract shall be submitted in writing
to the City of Nashua within 10 calendar days of their arising. The writing shall state
clearly and in full detail the basis for Independent Contractor's question or position. The
City of Nashua representative shall render a decision within 15 calendar days. The City of
Nashua's decision on the matter is final. Any work affected by a conflict, error, omission,
or discrepancy which has been performed by Independent Contractor prior to having
received the City of Nashua's resolution shall be at Independent Contractor's risk and
expense. At all times, Independent Contractor shall carry on the work under this contract
and maintain and complete work in accordance with the requirements of the contract or
determination of the City of Nashua. Independent Contractor is responsible for requesting
clarification or interpretation and is solely liable for any cost or expense arising from its
failure to do so.

TERMINATION OF CONTRACT

A. TERMINATION, ABANDONMENT, OR SUSPENSION AT WILL. The City of Nashua, in its
sole discretion, shall have the right to terminate, abandon, or suspend all or part of the
project and contract at will. If the City of Nashua chooses to terminate, abandon, or
suspend all or part of the project, it shall provide Independent Contractor 10 days’ written
notice of its intent to do so.

If all or part of the project is suspended for more than 90 days, the suspension shall be
treated as a termination at will of all or part of the project and contract.

Upon receipt of notice of termination, abandonment, or suspension at will, Independent
Contractor shall:

Immediately discontinue work on the date and to the extent specified in the notice.
Place no further orders or subcontracts for materials, services, or facilities, other
than as may be necessary or required for completion of such portion of work
under the contract that is not terminated.

3. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or subcontracts to the extent they
relate to the performance of work terminated, abandoned, or suspended under the
notice, assign to the City of Nashua any orders or subcontracts specified in the
notice, and revoke agreements specified in the notice.

4. Not resume work after the effective date of a notice of suspension until receipt of

a written notice from the City of Nashua to resume performance.

Ne

In the event of a termination, abandonment, or suspension at will, Independent Contractor
shall receive all amounts due and not previously paid to Independent Contractor for work
satisfactorily completed in accordance with the contract prior to the date of the notice and

GC 4 of 13

attorney’s fees and court costs incident thereto which fees the LESSEE hereby covenants and
agrees to pay.

16. RIGHT TO TERMINATE FOR CONVENIENCE

16.01 The LANDLORD may terminate this LEASE AGREEMENT as a
result of its sale of Property, such termination to be 30 days prior to any transfer of title.
LANDLORD shall give LESSEE at least sixty (60) days’ notice, in writing, specifying in said
notice the day (and the time of day) of termination which shall be the date on which possession
of the Premises shall be surrendered

16.02 The LESSEE may terminate this LEASE AGREEMENT at any time by
giving at least thirty (30) days’ notice, in writing, specifying in said notice the day (and the time
of day) on which possession of the Premises will be surrendered. LANDLORD’S representative
shall have sufficient time to check the Premises prior to taking formal possession thereof. In the
event that the LESSEE shall terminate this LEASE AGREEMENT in accordance with the above
provisions, payment of rent shall cease at the end of the said thirty (30) day period or at the end
of the day on which possession shall be surrendered, whichever shall last occur.

17. SURRENDER OF THE PREMISES

17.01 In the event that the term or any extension thereof shall have expired or
terminated, the LESSEE shall peacefully quit and surrender to LANDLORD the Premises
together with all improvements, alternations or additions made by LESSEE which cannot be
removed without damaging the Premises. LESSEE shall remove all personal property and shall
repair any damage caused by such removal. LESSEE shall also return all keys and any copies of
keys to 1 Pine St. Ext at the end of the term or any extension thereof. LESSEE’s obligations to
observe or perform the covenants contained herein shall survive the expiration or termination of
this LEASE AGREEMENT.

18. INDEMNIFICATION AND RELEASE FROM LIABILITY

18.01 The LESSEE shall defend, indemnify and hold harmless the
LANDLORD, its officers, agents and employees, from and against any and all losses suffered by
the LANDLORD, its officers, agents and employees and any and all claims, liabilities or
penalties asserted again the LANDLORD, its officers, agents and employees by or on behalf of
any person on account of, based on or resulting from, arising out of (or which may be claimed to
arise out of) the acts or omissions of the LESSEE or from the use, alterations or maintenance of
the Premises. This covenant shall survive the termination of this agreement.

19. MISCELLANEOUS

19.01 LANDLORD’s Agents. All rights and obligations of LANDLORD under
this LEASE AGREEMENT may be performed or exercised by such agents as LANDLORD may
select.

19.02 Notice. Any notice by a party hereto to the other party shall be deemed to
have been duly delivered or given at the time of mailing by registered or certified mail, postdate
prepaid, in a United States Post Office to the address first listed above.

19.03 Extent of Instrument, Choice of Laws, Amendment, etc. This LEASE
AGREEMENT, which may be executed in a number of counterparts, each of which shall have

compensation for work thereafter completed as specified in the notice. No amount shall be
allowed or paid for anticipated profit on unperformed services or other unperformed work.

B. TERMINATION FOR CAUSE This agreement may be terminated by the City of Nashua on
10 calendar day’s written notice to Independent Contractor in the event of a failure by
Independent Contractor to adhere to any or all the terms and conditions of the contract or
for failure to satisfactorily, in the sole opinion of the City of Nashua, to complete or make
sufficient progress on the work in a timely and professional manner. Independent
Contractor shall be given an opportunity for consultation with the City of Nashua prior to
the effective date of the termination. Independent Contractor may terminate the contract
on 10 calendar days written notice if, through no fault of Independent Contractor, the City
of Nashua fails to pay Independent Contractor for 45 days after the date of approval by the
City of Nashua of any Application for Payment.

Upon receipt of notice of termination for cause, Independent Contractor shall:

1. Immediately discontinue work on the date and to the extent specified in the notice.

Provide the City of Nashua with a list of all unperformed services.

Place no further orders or sub-contracts for materials, services, or facilities, other

than as may be necessary or required for completion of such portion of work

under the contract that is not terminated.

4. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or sub contracts to the extent they
relate to the performance of work terminated, abandoned, or suspended under the
notice, assign to the City of Nashua any orders or sub contracts specified in the
notice, and revoke agreements specified in the notice.

5. Not resume work after the effective date of a notice of termination unless and
until receipt of a written notice from the City of Nashua to resume performance.

wd

In the event of a termination for cause, Independent Contractor shall receive all amounts
due and not previously paid to Independent Contractor for work satisfactorily completed
in accordance with the contract prior to the date of the notice, less all previous payments.
No amount shall be allowed or paid for anticipated profit on unperformed services or other
unperformed work. Any such payment may be adjusted to the extent of any additional
costs occasioned to the City of Nashua by reasons of Independent Contractor's failure.
Independent Contractor shall not be relieved of liability to the City of Nashua for damages
sustained from the failure, and the City of Nashua may withhold any payment to the
Independent Contractor until such time as the exact amount of damages due to the City of
Nashua is determined. All claims for payment by the Independent Contractor must be
submitted to the City of Nashua within 30 days of the effective date of the notice of
termination.

If after termination for the failure of Independent Contractor to adhere to any of the terms
and conditions of the contract or for failure to satisfactorily, in the sole opinion of the City
of Nashua, to complete or make sufficient progress on the work in a timely and professional
manner, it is determined that Independent Contractor had not so failed, the termination
shall be deemed to have been a termination at will. In that event, the City of Nashua shall,
if necessary, make an adjustment in the compensation paid to Independent Contractor such
that Independent Contractor receives total compensation in the same amount as it would
have received in the event of a termination-at-will.

GC 5 of 13

10.

11.

C. GENERAL PROVISIONS FOR TERMINATION Upon termination of the contract, the City
of Nashua may take over the work and prosecute it to completion by agreement with
another party or otherwise. In the event Independent Contractor shall cease conducting
business, the City of Nashua shall have the right to solicit applications for employment
from any employee of the Independent Contractor assigned to the performance of the
contract.

Neither party shall be considered in default of the performance of its obligations hereunder
to the extent that performance of such obligations is prevented or delayed by any cause,
existing or future, which is beyond the reasonable control of such party. Delays arising
from the actions or inactions of one or more of Independent Contractor's principals,
officers, employees, agents, subcontractors, consultants, vendors, or suppliers are
expressly recognized to be within Independent Contractor's control.

DISPUTE RESOLUTION. — The parties shall attempt to resolve any dispute related to this
contract as follows. Either party shall provide to the other party, in writing and with full
documentation to verify and substantiate its decision, its stated position concerning the
dispute. No dispute shall be considered submitted and no dispute shall be valid under this
provision unless and until the submitting party has delivered the written statement of its
position and full documentation to the other party. The parties shall then attempt to resolve
the dispute through good faith efforts and negotiation between the City of Nashua
Representative and an Independent Contractor Representative. At all times, Independent
Contractor shall carry on the work under this contract and maintain and complete work in
accordance with the requirements of the contract or determination or direction of the City
of Nashua. If the parties are unable to resolve their dispute as described above within 30
days, if requested in writing by either the City of Nashua or the Independent Contractor
within 14 days after the 30 days described above,, the parties shall attempt to resolve the
dispute by entering into structured non-binding negotiations with the assistance of a
mediator on a without prejudice basis. The mediator shall be appointed by agreement of
the parties, which agreement shall not be unreasonably withheld. If the parties cannot agree
to a mediator within 30 days or the dispute cannot be settled within a period of thirty (30)
days with the mediator, the parties’ reserve the nght to pursue any available legal and/or
equitable remedies for any breaches of this contract except as that right may be limited by
the terms of this contract.

NO DAMAGES FOR DELAY Apart from a written extension of time, no payment,
compensation, or adjustment of any kind shall be made to Independent Contractor for
damages because of hindrances or delays in the progress of the work from any cause, and
Independent Contractor agrees to accept in full satisfaction of such hindrances and delays
any extension of time that the City of Nashua may provide.

INSURANCE Independent Contractor shall carry and maintain in effect during the
performance of services under this contract:

> General Liability insurance in the amount of $1,000,000 per occurrence;
$2,000,000 aggregate;

> $1,000,000 Combined Single Limit Automobile Liability; *Coverage must include
all owned, non-owned and hired vehicles ;

> Professional Liability insurance in the amount of $1,000,000; and

GC 6 of 13

> Workers’ Compensation Coverage in compliance with the State of New
Hampshire statutes, $100,000/$500,000/$100,000.

Independent Contractor shall maintain in effect at all times during the performance under
this contract all specified insurance coverage with insurers. None of the requirements as
to types and limits to be maintained by Independent Contractor are intended to and shall
not in any manner limit or qualify the liabilities and obligations assumed by Independent
Contractor under this contract. The City of Nashua shall not maintain any insurance on
behalf of Independent Contractor. Subcontractors are subject to the same insurance
requirements as Independent Contractor and it shall be the Independent Contractor’s
responsibility to ensure compliance of this requirement.

Independent Contractor will provide the City of Nashua with certificates of insurance for
coverage as listed below and endorsements affecting coverage required by the contract.
The City of Nashua requires thirty days written notice of cancellation or material change
in coverage. The certificates and endorsements for each insurance policy must be signed
by a person authorized by the insurer and who is licensed by the State of New Hampshire.
General Liability, Employers’ Liability and Auto Liability policies must name the
City of Nashua as an additional insured and reflect on the certificate of insurance.
Independent Contractor is responsible for filing updated certificates of insurance with the
City of Nashua's Risk Management Department during the life of the contract.

> All deductibles and self-insured retentions shall be fully disclosed in the
certificate(s) of insurance.

> If aggregate limits of less than $2,000,000 are imposed on bodily injury and
property damage, Independent Contractor must maintain umbrella liability
insurance of at least $1,000,000. All aggregates must be fully disclosed on the
required certificate of insurance.

> The specified insurance requirements do not relieve Independent Contractor of its
responsibilities or limit the amount of its liability to the City of Nashua or other
persons, and Independent Contractor is encouraged to purchase such additional
insurance, as it deems necessary.

>» The insurance provided herein is primary, and no insurance held or owned by the
City of Nashua shall be called upon to contribute to a loss.

> Independent Contractor is responsible for and required to remedy all damage or
loss to any property, including property of the City of Nashua, caused in whole or
part by Independent Contractor or anyone employed, directed, or supervised by
Independent Contractor.

12. INDEMNIFICATION Regardless of any coverage provided by any insurance, Independent
Contractor agrees to indemnify and hold harmless the City of Nashua, its agents, officials,
employees and authorized representatives and their employees from and against any and
all suits, causes of action, legal or administrative proceedings, arbitrations, claims,
demands, damages, liabilities, interest, attorney’s fees, costs and expenses of any kind or
nature in any manner caused, occasioned, or contributed to in whole or in part by reason of
any negligent act, omission, or fault or willful misconduct, whether active or passive, of
Independent Contractor or of anyone acting under its direction or control or on its behalf
in connection with or incidental to the performance of this contract. Independent
Contractor’s indemnity and hold harmless obligations, or portions thereof, shall not apply
to liability caused by the sole negligence or willful misconduct of the party indemnified or
held harmless.

GC 7 of 13