Search

B. CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility OWNER
(and OWNER, if OWNER is performing the other work with OWNER’s employees) proper and safe access to the Site
and a reasonable opportunity for the introduction and storage of materials and equipment and the execution of such
other work and shall properly coordinate the Work with theirs. Unless otherwise provided in the Contract Documents,
CONTRACTOR shall do all cutting, fitting, and patching of the Work that may be required to properly connect or
otherwise make its several parts come together and properly integrate with such other work. CONTRACTOR shall not
endanger any work of others by cutting, excavating, or otherwise altering their work and will only cut or alter their
work with the written consent of ENGINEER and the others whose work will be affected. The duties and
responsibilities of CONTRACTOR under this paragraph are for the benefit of such utility OWNERs and other
contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said direct contracts
between OWNER and such utility OWNERs and other contractors.

C. If the proper execution or results of any part of CONTRACTOR’s Work depends upon work performed by others
under this Article 7, CONTRACTOR shall inspect such other work and promptly report to ENGINEER in writing any
delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and
results of CONTRACTOR’s Work. CONTRACTOR’s failure to so report will constitute an acceptance of such other
work as fit and proper for integration with CONTRACTOR’s Work except for latent defects and deficiencies in such
other work.

7.02 Coordination

A. If OWNER intends to contract with others for the performance of other work on the Project at the Site, the
following will be set forth in Supplementary Conditions:

1. The individual or entity who will have authority and responsibility for coordination of the activities among the
various contractors will be identified;

2. The specific matters to be covered by such authority and responsibility will be itemized; and
3. The extent of such authority and responsibilities will be provided.

B. Unless otherwise provided in the Supplementary Conditions, OWNER shall have sole authority and responsibility
for such coordination,

ARTICLE 8 - OWNER'S RESPONSIBILITIES

8.01 Communications to Contractor

A. Except as otherwise provided in these General Conditions, OWNER shall issue all communications to
CONTRACTOR through ENGINEER.

8.02 Replacement of ENGINEER

A. In case of termination of the employment of ENGINEER, OWNER shall appoint and whose status under the
Contract Documents shall be that of the former ENGINEER.

8.03 Furnish Data
A. OWNER shall promptly furnish the data required of OWNER under the Contract Documents.
8.04 Pay Promptly When Due

A. OWNER shall make payments to CONTRACTOR promptly when they are due as provided in paragraphs 14.02.C
and 14.07.C,

GC - 32 of 53

8.05 Lands and Easements; Reports and Tests
A. OWNER's duties in respect of providing lands and easements and providing engineering surveys to establish
reference points are set forth in paragraphs 4.01 and 4.05. Paragraph 4.02 refers to OWNER's identifying and making
available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions and drawings of
physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been
utilized by ENGINEER in preparing the Contract Documents.
8.06 Insurance

See Article 5.
8.07 Change Orders
A. OWNER is obligated to execute Change Orders as indicated in paragraph 10.03.
8.08 Inspections, Tests, and Approvals
A, OWNER's responsibility in respect to certain inspections tests, and approvals is set forth in paragraph 13.03.B.
8.09 Limitations on OWNER's Responsibilities
A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for, CONTRACTOR's
means, methods, techniques, sequences, or procedures of construction, of the safety precautions and programs incident
thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of
the Work. OWNER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with the
Contract Documents.

8.10 Undisclosed Hazardous Environmental Condition

A. OWNER's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in paragraph
4.06

8.11 Evidence of Financial Arrangements

A. Ifand to the extent OWNER has agreed to furnish CONTRACTOR reasonable evidence that financial arrangements
have been made to satisfy OWNER's obligations under the Contract Documents, OWNER's responsibility in respect
thereof will be as set forth in the Supplementary Conditions.

ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION

9.01 OWNER?’s Representative

A. ENGINEER will be OWNER's representative during the construction periad. The duties and responsibilities and
the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the Contract
Documents and will not be changed without written consent of OWNER and ENGINEER,

9.02 Visits to Site

A. ENGINEER will make visits to the Site at intervals appropriate to the various stages of construction as ENGINEER
deems necessary in order to observe as an experienced and qualified design professional the progress that has been
made and the quality of the various aspects of CONTRACTOR's executed Work. Based on information obtained
during such visits and observations, ENGINEER, for the benefit of OWNER, will determine, in general, if the Work is
proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or

GC - 33 of 53

continuous inspections on the Site to check the quality or quantity of the Work. ENGINEER's efforts will be directed
toward providing for OWNER a greater degree of confidence that the completed Work will conform generally to the
Contract Documents. On the basis of such visits and observations, ENGINEER will keep OWNER informed of the
progress of the Work and will endeavor to guard OWNER against defective Work.

B. ENGINEER's visits and observations are subject to all the limitations on ENGENEER's authority and responsibility
set forth in paragraph 9.10, and particularly, but without limitation, during or as a result of ENGINEER's visits or
observations of CONTRACTOR's Work ENGINEER will not supervise, direct, control, or have authority over or be
responsible for CONTRACTOR's means, methods, techniques, sequences, or procedures of construction, or the safety
precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations
applicable to the performance of the Work.

9.03 Project Representative

A. If OWNER and ENGINEER agree, ENGINEER will furnish @ Resident Project Representative to assist
ENGINEER in providing more extensive observation of the Work. The responsibilities and authority and limitations
thereon of any such Resident Project Representative and assistants will be as provided in paragraph 9.10 and in the
Supplementary Conditions. If OWNER designates another representative or agent to represent OWNER at the Site
who is not ENGINEER’s Consultant, agent or employee, the responsibilities and authority and limitations thereof of
such other individual or entity will be as provided in the supplementary Conditions.

9.04 Clarifications and Interpretations

A. ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the requirements
of the Contract Documents as ENGINEER may determine necessary, which shall be consistent with the intent of and
reasonably inferable from the Contract Documents. Such written clarifications and interpretations will be binding on
OWNER and CONTRACTOR. [f OWNER and CONTRACTOR are unable to agree on entitlement to or on the
amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, that should be allowed as
a result of a written clarification or interpretation, a Claim may be made therefore as provided in paragraph 10.05,

9.05 Authorized Variations tn Work

A. ENGINEER may authorize minor variations in the Work from the requirements of the Contract documents which
do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept of
the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished by
a Field Order and will be binding on OWNER and also on CONTRACTOR, who shall perform the Work involved
promptly. If OWNER and CONTRACTOR are unable to agree on entitlement tc or on the amount or extent, if any, of
any adjustment in the Contract Price or Contract Times, or both, as a result of a Field Order, a Claim may be made
therefore as provided in paragraph 10.05.

9.06 Rejecting Defective Work

A ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, or that
ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will
prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the
Contract Documents. ENGINEER will also have authority to require special inspection or testing of the Work as
provided in paragraph 13.04, whether or not the Work is fabricated, installed, or completed.

9.07 Shop Drawings, Change Orders and Payments

A. In connection with ENGINEER's authority as to Shop Drawings and Samples, see paragraph 6.17.

B. In connection with ENGINEER's authority as to change orders, see Articles 10, 11, and 12.

GC - 34 of 53

C. In connection with ENGINEER's authority as to Applications for Payment, see Article 14.
9,08 Determinations for Unit Price Work

A ENGINEER will have authority to determine the actual quantities and classifications of items of Unit Price Work
performed by CONTRACTOR, and the written decisions of ENGINEER on such matters will be final, binding on
OWNER and CONTRACTOR and not subject to appeal (except as modified by ENGINEER to reflect changed factual
conditions).

9.09 Decisions on Requirements of Contract Documents and Acceptability af Wark

A. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the
acceptability of the Work there under. Claims, disputes and other matters relating to the acceptability of the Work, the
quantities and classifications of Unit Price Work, the interpretation of the requirements of the Contract documents
pertaining to the performance of the Work, and Claims seeking changes in the Contract Price or Contract Times will be
referred initially to ENGINEER in writing in accordance with the provisions of paragraph 10.05, with a request for a
formal decision.

B. When functioning as interpreter and judge under this paragraph 9.09, ENGINEER will not be liable in connection
with any interpretation or decision rendered in such capacity. The rendering of a decision by ENGINEER pursuant to
this paragraph 9.09 with respect to any such Claim, dispute, or other matter (except any which have been waived by the
making or acceptance of final payment as provided in paragraph 14.07) will be a condition precedent to any exercise
by OWNER or CONTRACTOR of such rights or remedies as either may otherwise have under the Contract
Documents or by Laws or Regulations in respect of any such Claim, dispute, or other matter,

9.10 Limitations on ENGINEER'S Authority and Responsibilities

A. Neither ENGINEER’s authority or responsibility under this Article 9 or under any other provision of the Contract
Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority or
responsibility or the undertaking, exercise, or performance of any authority or responsibility by ENGINEER shall
create, impose, or give rise to any duty in contract, tort, or otherwise owed by ENGINEER to CONTRACTOR, any
Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them.

B. ENGINEER will not supervise, direct, conirol, or have authority over or be responsible for CONTRACTOR's
means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident
thereto, or for any failure of CONTRACTOR ito comply with Laws and Regulations applicable to the performance of
the Work. ENGINEER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with
the Contract Documents.

C. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor, any
Supplier, or of any other individual or entity performing any of the Work.

D. ENGINEER's review of the final Application for Payment and accompanying documentation and all maintenance
and operating instructions, schedules, guarantees, Bonds, certificates of inspection, tests and approvals, and other
documentation required to be delivered by paragraph 14.07.A will only be to determine generally that their content
complies with the requirements of, and in the case of certificates or inspections, tests, and approvals that the results
certified indicate compliance with the Contract Documents.

E. The limitations upon authority and responsibility set forth in this paragraph 9.10 shall also apply to ENGINEER's
Consultants, Resident Project Representative, and assistants.

GC - 35 of 53

ARTICLE 10 - CHANGES IN THE WORK; CLAIMS

10.01 Authorized Changes in the Work

A. Without invalidating the Agreement and without notice to any surety, OWNER may, at any time or from time to
time, order additions, deletions, or revisions in the Work by a Written Amendment or a Change Order, Upon receipt of
any such document, CONTRACTOR shall promptly proceed with the Work involved which will be performed under
the applicable conditions of the Contract Documents (except as otherwise specifically provided).

B. If OWNER and CONTRACTOR are unable to agree on entitlement to, or on the amount or extent, if any, of an
adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Change Order, a
Claim may be made therefore as provided in paragraph 10.05.

10.02 Unauthorized Changes in the Work

A. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times with
respect to any work performed that is not required by the Contract Documents as amended, modified, or supplemented
as provided in paragraph 3.04, except in the case of an emergency as provided in paragraph 6.16 or in the case of
uncovering Work as provided in paragraph 13.04.B.

10.03 Execution of Change Orders

A. OWNER and CONTRACTOR shall execute appropriate Change Orders recommended by ENGINEER (or Written
Amendments) covering:

1, Changes in the Work which are: (i) ordered by OWNER pursuant to paragraph 10.01.A, Gi} required because of
acceptance of defective Work under paragraph 13.08.A or OWNER's correction of defective Work under
paragraph 13.09, or (iti) agreed to by the parties;

2. Changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed
sum or amount of time for Work actually performed in accordance with a Change Order ; and

3. Changes in the Contract Price and Contract Times which embody the substance of any written decision

rendered by ENGINEER pursuant to paragraph 10.05; provided that, in lieu of executing any such Change
Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract
Documents and applicable Laws and Regulations, but during any such appeal, CONTRACTOR shall carry on the
Work and adhere to the progress schedule as provided in paragraph 6.18.A,

10.04 Notification to Surety

A. If notice of any change affecting the general scope of the Work or the provisions of the Contract Documents
(including, but not limited to, Contract Price or Contract Times) is required by the provisions of any Bond to be given
to a surety, the giving of any such notice will be CONTRACTOR's responsibility. The amount of each applicable
Bond will be adjusted to reflect the effect of any such change.

10.05 Disputes — Not Insurance Related

A. Notice: Written notice stating the general nature of each Claim, dispute, or other matter shall be delivered by the
claimant to ENGINEER and the other party to the Contract promptly (but in no event later than 10 days) after the start
of the event giving rise thereto. Notice of the amount or extent of the dispute, or other matter with supporting data
shall be delivered to the ENGINEER, Risk Management Department and the other party to the Contract within 60 days
after the start of such event. A dispute for an adjustment in Contract Price shall be prepared in accordance with the
provisions in paragraph 12.01.B. A dispute for an adjustment in Contract Time shall be prepared in accordance with
the provisions of paragraph 12.02.B. Each dispute shall be accompanied by claimant's written statement that the

GC - 36 of 53

adjustment disputed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The
opposing party shall submit any response to ENGINEER and the claimant within 30 days after receipt of the claimant's
last submittal (unless ENGINEER allows additional time).

B. ENGINEER'S Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the last
submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on such
dispute, or other matter will be final and binding upon CONTRACTOR unless:

1. An appeal from ENGINESR'S decision is taken within the time limits and in accordance with the dispute
resolution procedures set forth in Article 16; or

2. If no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to

appeal from ENGINEER's written decision is delivered by CONTRACTOR to the other and to ENGINEER
within 30 days after the date of such decision, and a formal proceeding is instituted by the appealing party in a
forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial
Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), to exercise
such rights or remedies as the appealing party may have the respect to such Claim, dispute, or other matter in
accordance with applicable Laws and Regulations.

C. If ENGINEER does not render a formal decision in writing within the time stated in paragraph 10.05.B, a decision
denying the dispute in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of the
claimant or the submittal of the opposing party, if any.

D. No dispute for an adjustment in Contract Price or Contract Times (or Milestones) will be valid if not submitted in

accordance with this paragraph 10.05.

ARTICLE 11 - COST OF THE WORK; CASH ALLOWANCES; UNIT PRICE WORK

11.01 Cost of the Work

A. Costs Included: The term Cost of the Work means the sum of all costs necessarily incurred and paid by
CONTRACTOR in the proper performance of the Werk. When the value of any Work covered by a Change Order or
when a Claim for an adjustment in Contract Price is determined on the basis of the Cost of the Work, the costs to be
reimbursed to CONTRACTOR will be only those additional or incremental costs required because of the change in the
Work or because of the event giving rise to the Claim. Except as otherwise may be agreed to in writing by OWNER,
such costs shall be in amounts no higher than those prevailing in the locality of the Project, shall include only the
following items, and shall not include any of the costs itemized in paragraph 11,.01.B.

1. Payroll costs for employees in the direct employ of CONTRACTOR in the performance of the Work under
schedules of job classifications agreed upon by OWNER and CONTRACTOR. Such employees shall include
without limitation superintendents, foremen, and other personnel employed full time at the Site. Payroll costs of
employees not employed full time on the Work shall be apportioned on the basis of their time spent on the Work.
Payroll costs shall include, but not be limited to, salaries and wages plus the cost of fringe benefits which shall
include social security contributions, unemployment, excise, and payroll taxes, workers’ compensation, health and
retirement benefits, bonuses, sick leave, vacation and holiday pay applicable thereto. The expenses of performing
Work outside of regular working hours, on Saturday, Sunday, or legal holidays, shall be included in the above to
the extent authorized by OWNER.

2. Cost of all materials and equipment furnished and incorporated in the Work, including costs of transportation
and storage thereof, and Suppliers' field services required in connection therewith. All cash discounts shall accrue
to CONTRACTOR unless OWNER deposits funds with CONTRACTOR with which to make payments, in which
case the cash discounts shall accrue to OWNER, All trade discounts, rebates and refunds and returns from sale of

GC - 37 of 53

MDX Medical Inc.

Signature: Cae Ww frets

Name: Eric W. Gross

Title: Executive VP & General Counsel

Date: 1/27/22

Customer

Signature:

Name:

Title:

Date:

surplus materials and equipment shall accrue to OWNER, and CONTRACTOR shall make provisions so that they
may be obtained.

3. Payments made by CONTRACTOR to Subcontractors for Work performed by Subcontractors. If required by
OWNER, CONTRACTOR shall obtain competitive bids from subcontractors acceptable to OWNER and
CONTRACTOR and shall deliver such bids to OWNER, who will then determine, with the advice of ENGINEER,
which bids, if any, will be acceptable. If any subcontract provides that the Subcontractor is to be paid on the basis
of Cost of the Work plus a fee, the Subcontractor's Cost of the Work and fee shall be determined in the same
manner as CONTRACTOR's Cost of the Work and fee as provided in this paragraph 11.01.

4. Costs of special consultants (including but not limited to engineers, architects, testing laboratories, surveyors,
attorneys, and accountants) employed for services specifically related to the Work.

5. Supplemental costs including the following:

a. The proportion of necessary transportation, travel, and subsistence expenses of CONTRACTOR's employees
incurred in discharge of duties connected with the Work.

b. Cost, including transportation and maintenance, of all materials, supplies, equipment, machinery,
appliances, office, and temporary facilities at the Site, and hand tools not owned by the workers, which are
consumed m_ the performance of the Work, and cost, less market value, of such items used but not consumed
which remain the property of CONTRACTOR.

c. Rentals of all construction equipment and machinery, and the parts thereof whether rented from
CONTRACTOR or others in accordance with rental agreements approved by OWNER with the advice of
ENGINEER, and the costs of transportation, loading, unloading, assembly, dismantling, and removal thereof.
All such costs shall be in accordance with the terms of said rental agreements. The rental of any such
equipment, machinery, or parts shall cease when the use thereof is no longer necessary for the Work.

6. Rental rates shall be determined as follows:

a. The base rates shall be those established in publications and revisions thereto entitled “Rental Rate Blue
Book for Construction Equipment” or the “Rental Rate Blue Book for Older Construction Equipment” as
published by K-IH, 1735 Technology Drive, Suite 401, San Jose, CA 95110-1313, Phone (408) 467-6700.

b. Attachments (e.g. tractor with ripper and dozer or tractor with loader and backhoe) will be included in the
hourly rental rate only when deemed essential to the work as determined the Engineer. When multiple
attachments are approved for use and are being used interchangeably, the attachment having the higher rental
rate shall be the only one included for payment.

«. No direct payment will be made for necessary accessories Gncluding replenishing blades, augers, teeth,
hoses, bits, etc.) if not listed in the Rental Rate Blue Book.

d. No compensation will be allowed for shop tools having a daily rental rate of less than $10 as set forth in
Section 18 of the Rental Rate Blue Book.

i. Hf ordered to use equipment not listed in the aforementioned publications, the Engineer will
establish a rental rate for such equipment. CONTRACTOR shall furnish cost data that might assist in
the establishment of such rental rate.

ii. Payment will be made for the actual time that such equipment is in operation on the work.

ili. Authorized standby time for idle equipment shall be paid at 50% of the specified rate, less the
estimated operating cost per hour. No markup will be added for overhead and profit.

GC - 38 of 53

iv. Rental rate paid as above provided shall include the cost of fuel, oil, lubrication, small tools,
necessary attachments, repairs and maintenance of any kind, depreciation, storage, insurance and all
incidentals. CONTRACTOR shall provide the Engineer with a complete Force Account Equipment
Listing for each piece of equipment utilized,

e. Sales, consumer, use, and other similar taxes related to the Work, and for which CONTRACTOR is liable,
imposed by Laws and Regulations.

f. Deposits lost for causes other than negligence of CONTRACTOR, any Subcontractor, or anyone directly or
indirectly employed by any of them or for whose acts any of them may be liable, and royalty payments and
fees for permits and licenses.

g. Losses and damages (and related expenses) caused by damage to the Work, not compensated by insurance
or otherwise, sustained by CONTRACTOR in connection with the performance of the Work, provided such
losses and damages have resulted from causes other than negligence of CONTRACTOR, any Subcontractor, or
anyone directly or indirectly employed by any of them or for whose acts any of them may be liable. Such
losses shall include settlements made with the written consent and approval of OWNER. No such losses,
damages and expenses shall be included in the Cost of the Work for the purpose of determining
CONTRACTOR's fee.

h, The cost of utilities, fuel, and sanitary facilities at the Site.

i. Minor expenses such as telegrams, long distance telephone calls, telephone service at the Site, expressage,
and similar petty cash items in connection with the Work.

j. When the Cost of the Work is used to determine the value of a Change Order or of a Claim, the cost of
premiums for additional Bonds and insurance required because of the changes in the Work or caused by the
event giving rise to the Claim

k. When all the Work is performed on the basis of cost-plus, the costs of premiums for all Bonds and insurance
CONTRACTOR is required by the Contract Documents to purchase and maintain.

B. Costs Excluded: The term Cost of the Work shall not include any of the following items:

1. Payroll costs and other compensation of CONTRACTOR's officers, executives, principals (of partnerships and
sole proprietorships), general managers, engineers, architects, estimators, attorneys, auditors, accountants,
purchasing and contracting agents, expediters, timekeepers, clerks, and other personnel employed by
CONTRACTOR, whether at the Site or in CONTRACTOR's principal or branch office for general administration of
the Work and not specifically included in the agreed upon schedule of job classifications referred to in paragraph
11.01.A.1 or specifically covered by paragraph 11.01.A.4, all of which are to be considered administrative costs
covered by the CONTRACTOR's fee.

2. Expenses of CONTRACTOR's principal and branch offices other than CONTRACTOR’s office at the Site.

3. Any part of CONTRACTOR's capital expense, including interest on CONTRACTOR's capital employed for the
Work and charges against CONTRACTOR for delinquent payments.

4. Costs due to the negligence of CONTRACTOR, any Subcontractor, or anyone directly or indirectly employed by
any of them or for whose acts any of them may be liable, including but not limited to, the correction of defective
Work, disposal of materials or equipment wrongly supplied, and making good any damage to property.

5. Other overheard or general expense costs of any kind and the costs of any item not specifically and expressly
included in paragraphs 11.01.A and 11.01.B.

GC - 39 of 53

C. CONTRACTOR's Fee: When all the Work is performed on the basis of cost-plus, CONTRACTOR's fee shall be
determined as set forth in the Agreement. When the value of any Work covered by a Change Order or when a Claim
for an adjustment in Contract Price is deterrnined on the basis of Cost of the Work, CONTRACTOR’s fee shall be
determined as set forth in paragraph 12.01.C.

D. Documentation: Whenever the cost of the Work for any purpose is to be determined pursuant to paragraphs
11.01.A. and 11.01.B, CONTRACTOR will establish and maintain records thereof in accordance with generally
accepted accounting practices and submit in a form acceptable to ENGINEER as itemized cost breakdown together
with supporting data.

11.02 Cash Allowances

A. It is understood that CONTRACTOR has included in the Contract Price all allowances so named in the Contract
Documents and shall cause the Work so covered to be performed for such sums as may be acceptable to OWNER and
ENGINEER. CONTRACTOR agrees that:

1. The allowances include the cost to CONTRACTOR (less any applicable trade discounts) of materials and
equipment required by the allowances to be delivered at the Site, and all applicable taxes; and

2. CONTRACTOR's costs for unloading and handling on the Site, labor, installation costs, overhead, profit, and
other expenses contemplated for the allowances have been included in the Contract Price and not in the
allowances, and no demand for additional payment on account of any of the foregoing will be valid.

B. Prior to final payment, an appropriate Change Order will be issued as recommended by ENGINEER to reflect actual
amounts due CONTRACTOR on account of Work covered by allowances, and the Contract Price shall be
correspondingly adjusted,

11.03 Unit Price Work

A. Where the Contract Documents provide that all or part of the Work is to be Unit Price Work, initially the Contract
Price will be deemed to include for all Unit Price Work an amount equal to the sum of the unit price for each separately
identified item of Unit Price Work times the estimated quantity of each item as indicated in the Agreement. The
estimated quantities of items of the Unit Price Work are not guaranteed and are solely for the purpose of comparison of
Bids and determining an initial Contract Price. Determinations of the actual quantities and classifications of Unit Price
Work performed by CONTRACTOR will be made by ENGINEER subjects to the provisions of paragraph 9.08

B. Each unit price will be deemed to include an amount considered by CONTRACTOR to be adequate to cover
CONTRACTOR's overhead and profit for each separately identified item.

ARTICLE 12 - CHANGE OF CONTRACT PRICE; CHANGE OF CONTRACT TIMES

12.01 Change of Contract Price

A. The Contract Price may only be changed by a Change Order or by a Written Amendment. Any Claim for an
adjustment in the Contract Price shall be based on written notice submitted by the party making the Claim to the
ENGINEER and the other party to the Contract in accordance with the provisions of paragraph 10.05.

B. The value of any Work covered by a Change Order or of any Claim for an adjustment in the Contract Price will be
determined as follows:

1. Where the Work involved is covered by unit prices contained in the Contract Documents, by application of such
unit prices to the quantities of the items involved (subject to the provisions of paragraph 11.03); or

GC - 40 of 53