Finance Committee

prepared in accordance with the provisions in paragraph 12.01.B. A dispute for an adjustment in Contract Time
shall be prepared in accordance with the provisions of paragraph 12.02.B. Each dispute shall be accompanied by
claimant's written statement that the adjustment disputed is the entire adjustment to which the claimant believes it
is entitled as a result of said event. The opposing party shall submit any response to ENGINEER and the
claimant within 30 days after receipt of the claimant's last submittal (unless ENGINEER allows additional time).

ARTICLE 10 - CHANGES IN THE WORK; CLAIMS

10.01 Authorized Changes in the Work

A. Without invalidating the Agreement and without notice to any surety, OWNER may, at any time or from time
to time, order additions, deletions, or revisions in the Work by a Written Amendment or a Change Order. Upon
receipt of any such document, CONTRACTOR shall promptly proceed with the Work involved which will be
performed under the applicable conditions of the Contract Documents (except as otherwise specifically
provided).

9.08 Determinations for Unit Price Work

A ENGINEER will have authority to determine the actual quantities and classifications of items of Unit Price
Work performed by CONTRACTOR, and the written decisions of ENGINEER on such matters will be final,
binding on OWNER and CONTRACTOR and not subject to appeal (except as modified by ENGINEER to reflect
changed factual conditions).

9.09 Decisions on Requirements of Contract Documents and Acceptability of Work

B. ENGINEER's visits and observations are subject to all the limitations on ENGINEER's authority and
responsibility set forth in paragraph 9.10, and particularly, but without limitation, during or as a result of
ENGINEER's visits or observations of CONTRACTOR's Work ENGINEER will not supervise, direct, control, or
have authority over or be responsible for CONTRACTOR's means, methods, techniques, sequences, or
procedures of construction, or the safety precautions and programs incident thereto, or for any failure of

8.06 Insurance

C. If the proper execution or results of any part of CONTRACTOR’s Work depends upon work performed by
others under this Article 7, CONTRACTOR shall inspect such other work and promptly report to ENGINEER in
writing any delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the
proper execution and results of CONTRACTOR’s Work. CONTRACTOR’s failure to so report will constitute
an acceptance of such other work as fit and proper for integration with CONTRACTOR’s Work except for latent

6.20 Indemnification

approval by ENGINEER relieve CONTRACTOR from responsibility for complying with the requirements of
paragraph 6.17.D.1.

F. Resubmittal Procedures
1. CONTRACTOR shall make corrections required by ENGINEER and shall return the required number of
corrected copies of Shop Drawings and submit as required new Samples for review and approval.

CONTRACTOR shall direct specific attention in writing to revisions other than the corrections called for by
ENGINEER on previous submittals.

6.18 Continuing the Work

ENGINEER may require to enable ENGINEER to review the submittal for the limited purposes required by
paragraph 6.17.E. The numbers of each Sample to be submitted will be as specified in the Specifications.

C. Where a Shop Drawing or Sample is required by the Contract Documents or the schedule of Shop Drawings
and Sample submittals acceptable to ENGINEER as required by paragraph 2.07, any related Work performed
prior to ENGINEER’s review and approval of the pertinent submittal will be at the sole expense and
responsibility of CONTRACTOR.

E. Protection of Utilities: The CONTRACTOR shall verify all utility locations prior to the start of construction.
This shall include, but not necessarily limited to: irrigation and drainage ditches, culverts, water lines, sewer
lines, telephone cables, cable television, gas lines and electric lines. Prior to the start of construction the
CONTRACTOR shall call Dig Safe System, Inc. 1-800-344-7233 (two full working days’ notice required). The
failure of any utility to subscribe to DIGS shall not relieve the CONTRACTOR from the responsibility of