Search

c. All information relative to means, methods, techniques, sequences, and procedures of construction and
safety precautions and programs incident thereto; and

d. CONTRACTOR shall also have reviewed and coordinated each Shop Drawing or Sample with other Shop
drawings and Samples and with the requirements of the Work and the Contract Documents.

2. Each submittal shall bear a stamp or specific written indication that CONTRACTOR has satisfied
CONTRACTOR’s obligations under the Contract Documents with respect to CONTRACTOR’s review and
approval of that submittal.

3. At the time of each submittal, CONTRACTOR shall give ENGINEER specific written notice of such variations,
if any, that the Shop Drawing or Sample submitted may have from the requirements of the Contract Documents,
such notice to be in a written communication separate from the submittal; and, in addition, shall cause a specific
notation to be made on each Shop Drawing and Sample submitted to ENGINEER for review and approval of each
such variation.

E. ENGINEER ’s Review

1. ENGINEER will timely review and approve Shop Drawings and Samples in accordance with the schedule of
Shop Drawings and Sample submittals acceptable to ENGINEER. ENGINEER’s review and approval will be
only to determine if the items covered by the submittals will, after installation or incorporation in the Work,
conform to the information given in the Contract Documents and be compatible with the design concept of the
completed Project as a functioning whole as indicated by the Contract Documents.

2.ENGINEER’s review and approval will not extend to means, methods, techniques, sequences, or procedures of
construction (except where a particular means, method, technique, sequence, or procedure of construction is
specifically and expressly called for the Contract Documents) or to safety precautions or programs incident
thereto. The review and approval of a separate item as such will not indicate approval of the assembly in which the
item functions.

3. ENGINEER’s review and approval of Shop Drawings or Samples shall not relieve CONTRACTOR from
responsibility for any variation from the requirements of the Contract Documents unless CONTRACTOR has in
writing called ENGINEER’s attention to each such variation at the time of each submittal as required by
paragraph 6.17.D.3 and ENGINEER has given written approval of each such variation by specific written notation
thereof incorporated in or accompanying the Shop Drawing or Sample approval; nor will any approval by
ENGINEER relieve CONTRACTOR from responsibility for complying with the requirements of paragraph
6.17.D.1.

F. Resubmittal Procedures

1. CONTRACTOR shall make corrections required by ENGINEER and shall return the required number of
corrected copies of Shop Drawings and submit as required new Samples for review and approval.
CONTRACTOR shall direct specific attention in writing to revisions other than the corrections called for by
ENGINEER on previous submittals.

6.18 Continuing the Work
A. CONTRACTOR shall carry on the Work and adhere to the progress schedule during all disputes or disagreements

with OWNER. No Work shall be delayed or postponed pending resolution of any disputes or disagreements, except as
permitted by paragraph 15.04 or as OWNER and CONTRACTOR may otherwise agree in writing.

GC - 30 of 54

6.19 CONTRACTOR’s General Warranty and Guarantee

A. CONTRACTOR warrants and guarantees to OWNER, ENGINEER, and ENGINEER’s Consultants that all Work
will be in accordance with the Contract Documents and will not be defective. CONTRACTOR’s warranty and
guarantee hereunder excludes defects or damage caused by:

1. Abuse, modification, or improper maintenance or operation by persons other than CONTRACTOR,
Subcontractors, Suppliers, or any other individual or entity for whom CONTRACTOR is responsible; or

2. Normal wear and tear under normal usage.

B. CONTRACTOR’s obligation to perform and complete the Work in accordance with the Contract Documents shall
be absolute. None of the following will constitute an acceptance of Work that is not in accordance with the Contract
Documents or a release of CONTRACTOR’s obligation to perform the Work in accordance with the Contract
Documents:

1. Observations by ENGINEER;
2. Recommendation by ENGINEER or payment by OWNER OF ANY PROGRESS OR FINAL PAYMENT;

3. The issuance of a certificate of Substantial Completion by ENGINEER or any payment related thereof by
OWNER:

4. Use or occupancy of the Work or any part thereof by OWNER;
5. Any acceptance by OWNER or any failure to do so;

6. Any review and approval of a Shop Drawing or Sample submittal or the issuance of a notice of acceptability
by ENGINEER;

7. Any inspection, test, or approval by others; or
8. Any correction of defective Work by OWNER.
6.20 Indemnification

A. Regardless of the coverage provided by any insurance, Contractor agrees to indemnify and shall defend and hold
harmless the City, its agents, officials, employees and authorized representatives and their employees from and against
any and all suits, causes of action, legal or administrative proceedings, arbitrations, claims, demands, damages,
liabilities, interest, attorneys’ fees, costs and expenses of any kind or nature in any manner caused, occasioned, or
contributed to in whole or in part by reason of any negligent act, omission, or fault or willful misconduct, whether
active or passive, of Contractor or of anyone acting under its direction or control or on its behalf in connection with or
incidental to the performance of this contract. Contractor's indemnity, defense and hold harmless obligations, or
portions thereof, shall not apply to liability caused by the sole negligence or willful misconduct of the party
indemnified or held harmless.

B. In any and all claims against OWNER or ENGINEER, agents, officers, directors, partners, or employees by any
employee (or the survivor or personal representative of such employee) of CONTRACTOR, any Subcontractor, any
Supplier, or any individual or entity directly or indirectly employed by any of them to perform any of the Work, or
anyone for whose acts any of them may be liable, the indemnification obligation under paragraph 6.20.A shall not be
limited in any way by any limitation on the amount or type of damages, compensation, or benefits payable by or for
CONTRACTOR or any such Subcontractor, Supplier, or other individual or entity.

GC - 31 of 54

C. The indemnification obligations of CONTRACTOR under paragraph 6.20.A shall not extend to the liability of
ENGINEER and ENGINEER’s Consultants or to the officers, directors, partners, employees, agents, and other
consultants and subcontractors of each and any of them arising out of:

The preparation or approval of, or the failure to prepare or approve, maps, Drawings, opinions, reports, surveys,
Change Orders, designs, or Specifications.

ARTICLE 7 - OTHER WORK

7.01 Related Work at Site

A. OWNER may perform other work related to the Project at the Site by OWNER’s employees, or let other direct
contracts therefore, or have other work performed by utility Owner’s. If such other work is not noted in the Contract
Documents, then:

1. Written notice thereof will be given to CONTRACTOR prior to starting any such other work; and

2. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of any
adjustment in the Contract Price or Contract Times that should be allowed as a result of such other work, a Claim
may be made therefore as provided in paragraph 10.05.

B. CONTRACTOR shall afford each other contractor who is a party to such a direct contract and each utility
OWNER (and OWNER, if OWNER is performing the other work with OWNER’s employees) proper and safe access
to the Site and a reasonable opportunity for the introduction and storage of materials and equipment and the execution
of such other work and shall properly coordinate the Work with theirs. Unless otherwise provided in the Contract
Documents, CONTRACTOR shall do all cutting, fitting, and patching of the Work that may be required to properly
connect or otherwise make its several parts come together and properly integrate with such other work.
CONTRACTOR shall not endanger any work of others by cutting, excavating, or otherwise altering their work and
will only cut or alter their work with the written consent of ENGINEER and the others whose work will be affected.
The duties and responsibilities of CONTRACTOR under this paragraph are for the benefit of such utility OWNERs
and other contractors to the extent that there are comparable provisions for the benefit of CONTRACTOR in said
direct contracts between OWNER and such utility OWNERs and other contractors.

C. If the proper execution or results of any part of CONTRACTOR’s Work depends upon work performed by others
under this Article 7, CONTRACTOR shall inspect such other work and promptly report to ENGINEER in writing any
delays, defects, or deficiencies in such other work that render it unavailable or unsuitable for the proper execution and
results of CONTRACTOR’s Work. CONTRACTOR’: failure to so report will constitute an acceptance of such other
work as fit and proper for integration with CONTRACTOR’s Work except for latent defects and deficiencies in such
other work.

7.02 Coordination

A. If OWNER intends to contract with others for the performance of other work on the Project at the Site, the
following will be set forth in Supplementary Conditions:

1. The individual or entity who will have authority and responsibility for coordination of the activities among the
various contractors will be identified;

2. The specific matters to be covered by such authority and responsibility will be itemized; and
3. The extent of such authority and responsibilities will be provided.

B. Unless otherwise provided in the Supplementary Conditions, OWNER shall have sole authority and responsibility
for such coordination.

GC - 32 of 54

ARTICLE 8 - OWNER'S RESPONSIBILITIES

8.01 Communications to Contractor

A. Except as otherwise provided in these General Conditions, OWNER shall issue all communications to
CONTRACTOR through ENGINEER.

8.02 Replacement of ENGINEER

A. In case of termination of the employment of ENGINEER, OWNER shall appoint and whose status under the
Contract Documents shall be that of the former ENGINEER.

8.03 Furnish Data
A. OWNER shall promptly furnish the data required of OWNER under the Contract Documents.
8.04 Pay Promptly When Due

A. OWNER shall make payments to CONTRACTOR promptly when they are due as provided in paragraphs 14.02.C
and 14.07.C.

8.05 Lands and Easements; Reports and Tests
A. OWNER's duties in respect of providing lands and easements and providing engineering surveys to establish
reference points are set forth in paragraphs 4.01 and 4.05. Paragraph 4.02 refers to OWNER's identifying and making
available to CONTRACTOR copies of reports of explorations and tests of subsurface conditions and drawings of
physical conditions in or relating to existing surface or subsurface structures at or contiguous to the Site that have been
utilized by ENGINEER in preparing the Contract Documents.
8.06 Insurance

See Article 5.
8.07 Change Orders
A. OWNER is obligated to execute Change Orders as indicated in paragraph 10.03.
8.08 Inspections, Tests, and Approvals
A. OWNER's responsibility in respect to certain inspections tests, and approvals is set forth in paragraph 13.03.B.
8.09 Limitations on OWNER'S Responsibilities
A. The OWNER shall not supervise, direct, or have control or authority over, nor be responsible for,
CONTRACTOR's means, methods, techniques, sequences, or procedures of construction, of the safety precautions and
programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to
the performance of the Work. OWNER will not be responsible for CONTRACTOR's failure to perform the Work in
accordance with the Contract Documents.

8.10 Undisclosed Hazardous Environmental Condition

A. OWNER's responsibility in respect to an undisclosed Hazardous Environmental Condition is set forth in paragraph
4.06

GC - 33 of 54

8.11 Evidence of Financial Arrangements

A. If and to the extent OWNER has agreed to furnish CONTRACTOR reasonable evidence that financial
arrangements have been made to satisfy OWNER's obligations under the Contract Documents, OWNER's
responsibility in respect thereof will be as set forth in the Supplementary Conditions.

ARTICLE 9 - ENGINEER'S STATUS DURING CONSTRUCTION

9.01 OWNER’s Representative

A. ENGINEER will be OWNER's representative during the construction period. The duties and responsibilities and
the limitations of authority of ENGINEER as OWNER's representative during construction are set forth in the
Contract Documents and will not be changed without written consent of OWNER and ENGINEER.

9.02 Visits to Site

A. ENGINEER will make visits to the Site at intervals appropriate to the various stages of construction as ENGINEER
deems necessary in order to observe as an experienced and qualified design professional the progress that has been
made and the quality of the various aspects of CONTRACTOR's executed Work. Based on information obtained
during such visits and observations, ENGINEER, for the benefit of OWNER, will determine, in general, if the Work is
proceeding in accordance with the Contract Documents. ENGINEER will not be required to make exhaustive or
continuous inspections on the Site to check the quality or quantity of the Work. ENGINEER's efforts will be directed
toward providing for OWNER a greater degree of confidence that the completed Work will conform generally to the
Contract Documents. On the basis of such visits and observations, ENGINEER will keep OWNER informed of the
progress of the Work and will endeavor to guard OWNER against defective Work.

B. ENGINEER's visits and observations are subject to all the limitations on ENGINEER's authority and responsibility
set forth in paragraph 9.10, and particularly, but without limitation, during or as a result of ENGINEER's visits or
observations of CONTRACTOR's Work ENGINEER will not supervise, direct, control, or have authority over or be
responsible for CONTRACTOR's means, methods, techniques, sequences, or procedures of construction, or the safety
precautions and programs incident thereto, or for any failure of CONTRACTOR to comply with Laws and
Regulations applicable to the performance of the Work.

9.03 Project Representative

A. If OWNER and ENGINEER agree, ENGINEER will furnish a Resident Project Representative to assist
ENGINEER in providing more extensive observation of the Work. The responsibilities and authority and limitations
thereon of any such Resident Project Representative and assistants will be as provided in paragraph 9.10 and in the
Supplementary Conditions. If OWNER designates another representative or agent to represent OWNER at the Site
who is not ENGINEER's Consultant, agent or employee, the responsibilities and authority and limitations thereof of
such other individual or entity will be as provided in the supplementary Conditions.

9.04 Clarifications and Interpretations

A. ENGINEER will issue with reasonable promptness such written clarifications or interpretations of the requirements
of the Contract Documents as ENGINEER may determine necessary, which shall be consistent with the intent of and
reasonably inferable from the Contract Documents. Such written clarifications and interpretations will be binding on
OWNER and CONTRACTOR. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the
amount or extent, if any, of any adjustment in the Contract Price or Contract Times, or both, that should be allowed as
a result of a written clarification or interpretation, a Claim may be made therefore as provided in paragraph 10.05.

GC - 34 of 54

9.05 Authorized Variations in Work

A. ENGINEER may authorize minor variations in the Work from the requirements of the Contract documents which
do not involve an adjustment in the Contract Price or the Contract Times and are compatible with the design concept
of the completed Project as a functioning whole as indicated by the Contract Documents. These may be accomplished
by a Field Order and will be binding on OWNER and also on CONTRACTOR, who shall perform the Work involved
promptly. If OWNER and CONTRACTOR are unable to agree on entitlement to or on the amount or extent, if any, of
any adjustment in the Contract Price or Contract Times, or both, as a result of a Field Order, a Claim may be made
therefore as provided in paragraph 10.05.

9.06 Rejecting Defective Work

A ENGINEER will have authority to disapprove or reject Work which ENGINEER believes to be defective, or that
ENGINEER believes will not produce a completed Project that conforms to the Contract Documents or that will
prejudice the integrity of the design concept of the completed Project as a functioning whole as indicated by the
Contract Documents. ENGINEER will also have authority to require special inspection or testing of the Work as
provided in paragraph 13.04, whether or not the Work is fabricated, installed, or completed.

9.07 Shop Drawings, Change Orders and Payments

A. In connection with ENGINEER's authority as to Shop Drawings and Samples, see paragraph 6.17.
B. In connection with ENGINEER's authority as to change orders, see Articles 10, 11, and 12.

C. In connection with ENGINEER's authority as to Applications for Payment, see Article 14.

9.08 Determinations for Unit Price Work

A ENGINEER will have authority to determine the actual quantities and classifications of items of Unit Price Work
performed by CONTRACTOR, and the written decisions of ENGINEER on such matters will be final, binding on

OWNER and CONTRACTOR and not subject to appeal (except as modified by ENGINEER to reflect changed factual
conditions).

9.09 Decisions on Requirements of Contract Documents and Acceptability of Work

A. ENGINEER will be the initial interpreter of the requirements of the Contract Documents and judge of the
acceptability of the Work there under. Claims, disputes and other matters relating to the acceptability of the Work, the
quantities and classifications of Unit Price Work, the interpretation of the requirements of the Contract documents
pertaining to the performance of the Work, and Claims seeking changes in the Contract Price or Contract Times will
be referred initially to ENGINEER in writing in accordance with the provisions of paragraph 10.05, with a request for
a formal decision.

B. When functioning as interpreter and judge under this paragraph 9.09, ENGINEER will not be liable in connection
with any interpretation or decision rendered in such capacity. The rendering of a decision by ENGINEER pursuant to
this paragraph 9.09 with respect to any such Claim, dispute, or other matter (except any which have been waived by
the making or acceptance of final payment as provided in paragraph 14.07) will be a condition precedent to any
exercise by OWNER or CONTRACTOR of such nights or remedies as either may otherwise have under the Contract
Documents or by Laws or Regulations in respect of any such Claim, dispute, or other matter.

9.10 Limitations on ENGINEER's Authority and Responsibilities
A. Neither ENGINEER's authority or responsibility under this Article 9 or under any other provision of the Contract
Documents nor any decision made by ENGINEER in good faith either to exercise or not exercise such authority or

responsibility or the undertaking, exercise, or performance of any authority or responsibility by ENGINEER shall

GC - 35 of 54

create, impose, or give rise to any duty in contract, tort, or otherwise owed by ENGINEER to CONTRACTOR, any
Subcontractor, any Supplier, any other individual or entity, or to any surety for or employee or agent of any of them.

B. ENGINEER will not supervise, direct, control, or have authority over or be responsible for CONTRACTOR's
means, methods, techniques, sequences, or procedures of construction, or the safety precautions and programs incident
thereto, or for any failure of CONTRACTOR to comply with Laws and Regulations applicable to the performance of
the Work. ENGINEER will not be responsible for CONTRACTOR's failure to perform the Work in accordance with
the Contract Documents.

C. ENGINEER will not be responsible for the acts or omissions of CONTRACTOR or of any Subcontractor, any
Supplier, or of any other individual or entity performing any of the Work.

D. ENGINEER's review of the final Application for Payment and accompanying documentation and all maintenance
and operating instructions, schedules, guarantees, Bonds, certificates of inspection, tests and approvals, and other
documentation required to be delivered by paragraph 14.07.A will only be to determine generally that their content
complies with the requirements of, and in the case of certificates or inspections, tests, and approvals that the results
certified indicate compliance with the Contract Documents.

E. The limitations upon authority and responsibility set forth in this paragraph 9.10 shall also apply to ENGINEER's
Consultants, Resident Project Representative, and assistants.

ARTICLE 10 - CHANGES IN THE WORK; CLAIMS

10.01 Authorized Changes in the Work

A. Without invalidating the Agreement and without notice to any surety, OWNER may, at any time or from time to
time, order additions, deletions, or revisions in the Work by a Written Amendment or a Change Order. Upon receipt
of any such document, CONTRACTOR shall promptly proceed with the Work involved which will be performed
under the applicable conditions of the Contract Documents (except as otherwise specifically provided).

B. If OWNER and CONTRACTOR are unable to agree on entitlement to, or on the amount or extent, if any, of an
adjustment in the Contract Price or Contract Times, or both, that should be allowed as a result of a Change Order, a
Claim may be made therefore as provided in paragraph 10.05.

10.02 Unauthorized Changes in the Work

A. CONTRACTOR shall not be entitled to an increase in the Contract Price or an extension of the Contract Times
with respect to any work performed that is not required by the Contract Documents as amended, modified, or
supplemented as provided in paragraph 3.04, except in the case of an emergency as provided in paragraph 6.16 or in
the case of uncovering Work as provided in paragraph 13.04.B.

10.03 Execution of Change Orders

A. OWNER and CONTRACTOR shall execute appropriate Change Orders recommended by ENGINEER (or Written
Amendments) covering:

1. Changes in the Work which are: (i) ordered by OWNER pursuant to paragraph 10.01.A, (ii) required because of
acceptance of defective Work under paragraph 13.08.A or OWNER's correction of defective Work under
paragraph 13.09, or (iii) agreed to by the parties;

2. Changes in the Contract Price or Contract Times which are agreed to by the parties, including any undisputed
sum or amount of time for Work actually performed in accordance with a Change Order ; and

GC - 36 of 54

Welcoming Manchester Resolution CITY CLERK'S OFFICE
Board of Mayor and Alderman

Resolution Affirming Manchester, New Hampshire as a Welcoming City and to join the
Welcoming America Initiative, to help unite our community and ensure that all are welcome in
Manchester.

WHEREAS, fostering a welcoming environment for all individuals, regardless of race, ethnicity
or place of origin, enhances Manchester’s cultural fabric, economical growth, global
competitiveness and overall prosperity for current and future generations; and

WHEREAS, Manchester has long been recognized as a hospitable and welcoming place where
individuals, families and institutions thrive and the contributions of all are celebrated and valued:
and

WHEREAS, Manchester is committed to continue building a welcoming and neighborly
atmosphere in our community, where all people including immigrant newcomers are welcome,
accepted and integrated; and to encourage all residents of Manchester to do their part in reaching
out and welcoming ail! who live, work and visit Manchester; and

WHEREAS, community efforts that promote understanding and collaboration between log-time
residents and foreign born community members are crucial in encouraging and ensuring a
welcoming environment, such as Welcoming Manchester initiative: and

WHEREAS, Manchester encourages its business leaders, civic groups, other government
agencies and community institutions and residents to join in a community-wide effort to expand
prosperity and inclusion for all residents by implementing policies and practices that promote
integration; and

NOW, THEREFORE, the Board of Mayor and Alderman does hereby recognize on this gn day
of August Two Thousand and Sixteen, the Welcoming Manchester Initiative as he}ping to unite
our community and proudly joins the Welcoming America Initiative as one of the many cities
and municipalities that already are Welcoming Communities.

Finance Committee — 03/02/2022 Page 8

Thank you Mr. Mayor. So as you know the city has many miles of sidewalk. This project working collaboratively with
Nashua Regional Planning Commission will allow us to inventory all of that sidewalk and assess the condition of it,
defining where we have problems that don’t meet ADA requirements. This project as | said, will be joint with them. NRPC
will fund a crew of collection folks — two people, and the city will do the same, and we'll work collaboratively throughout all
the sidewalk segments and collect data.

As part of the effort, we will also seek public input. There will be a public portal where people can pin on a map and be
able to submit a comment about where they see a current issue that we should consider for future improvement and will
also present the findings and other information at public meetings. All this data will be collected in accordance with the
State-wide asset data exchange which is a State-wide system for conformity and I’d be happy to answer any questions if
anyone has one.

Mayor Donchess

Alderman Klee?

Alderman Klee

Thank you Mr. Mayor and thank you Mr. Hudson. Our streets are in some rough shape throughout the entire city. |
appreciate the public portal. Would that be similar to what we did for the Master Plan where people can just pin a street
and then put a comment saying there are potholes, not potholes obviously, but broken sidewalk or that there is a sidewalk
needed in this area. Is that the type of commenting that you'll be looking for?

Dan Hudson, City Engineer

Yes, that’s exactly right. That’s my understanding. That was found to be very effective for the Nashua planning process
and we intend to do the same thing here - cast a wide net and try to seek all input that people have. As we go through a
prioritization type of exercise too looking at a variety of factors which sidewalks are in close proximity to public buildings,
schools, that sort of thing and try to get our hands around prioritizing future improvement plans for certain sections. So
yeah, it will be an open process and we welcome everybody to comment.

Alderman Klee

Just a quick follow-up. | really do appreciate that. So just clarification - is this project just to look at current sidewalks that
exist or the potential for other sidewalks that just don’t exist? We often here some people talk about some of the main
streets, like Main-Dunstable, or something to that where there is no sidewalk for their children to walk to school. It’s
outside of the 1,000 feet but it’s still dangerous for their children to walk. So would they have the opportunity there as well
or is it just for the broken sidewalks?

Dan Hudson, City Engineer

We will be looking at the sidewalks that exist and assessing their condition but | do fully expect as part of this that people
can comment on where they would like to see sidewalks. There are some areas where we have a sidewalk and then we
have a gap and another sidewalk in areas we can look where that can be filled in. Then of course as you mentioned,
there are roads where people desire new sidewalks. So everything will be on the table in terms of gathering comment
information, but the list really will be prioritized to find out what we have and prioritize where the sections are that we
should focus rehab on the most.

Alderman Klee

Just one more quick. | know that you have been made aware of the grant for Locke Street and Whitney and that whole
project there. That was a grant that we received almost 5 years ago, | think, that did the sidewalks for those two areas
because of the walk to school. When we do this project and we get a list of the streets that need to be done will we
possibly try to work with our grant writer to see if there are any grants that could help us kind of accomplish this goal
especially those for the safe to school? | don’t know if that grant is still available. But different things like that so that we
can insure that we have less cost to our taxpayers. Will we be taking that into consideration?

Dan Hudson, City Engineer

Yes certainly. You know through the infrastructure funding that is coming from the federal government, we understand

3. Changes in the Contract Price and Contract Times which embody the substance of any written decision

rendered by ENGINEER pursuant to paragraph 10.05; provided that, in lieu of executing any such Change
Order, an appeal may be taken from any such decision in accordance with the provisions of the Contract
Documents and applicable Laws and Regulations, but during any such appeal, CONTRACTOR shall carry on the
Work and adhere to the progress schedule as provided in paragraph 6.18.A.

10.04 Notification to Surety

A. If notice of any change affecting the general scope of the Work or the provisions of the Contract Documents
(including, but not limited to, Contract Price or Contract Times) is required by the provisions of any Bond to be given
to a surety, the giving of any such notice will be CONTRACTOR's responsibility. The amount of each applicable
Bond will be adjusted to reflect the effect of any such change.

10.05 Disputes — Not Insurance Related

A. Notice: Written notice stating the general nature of each Claim, dispute, or other matter shall be delivered by the
claimant to ENGINEER and the other party to the Contract promptly (but in no event later than 10 days) after the start
of the event giving rise thereto. Notice of the amount or extent of the dispute, or other matter with supporting data
shall be delivered to the ENGINEER, Risk Management Department and the other party to the Contract within 60 days
after the start of such event. A dispute for an adjustment in Contract Price shall be prepared in accordance with the
provisions in paragraph 12.01.B. A dispute for an adjustment in Contract Time shall be prepared in accordance with
the provisions of paragraph 12.02.B. Each dispute shall be accompanied by claimant's written statement that the
adjustment disputed is the entire adjustment to which the claimant believes it is entitled as a result of said event. The
opposing party shall submit any response to ENGINEER and the claimant within 30 days after receipt of the claimant's
last submittal (unless ENGINEER allows additional time).

B. ENGINEER'S Decision: ENGINEER will render a formal decision in writing within 30 days after receipt of the
last submittal of the claimant or the last submittal of the opposing party, if any. ENGINEER's written decision on
such dispute, or other matter will be final and binding upon CONTRACTOR unless:

1. An appeal from ENGINEER'S decision is taken within the time limits and in accordance with the dispute
resolution procedures set forth in Article 16; or

2. If no such dispute resolution procedures have been set forth in Article 16, a written notice of intention to

appeal from ENGINEER's written decision is delivered by CONTRACTOR to the other and to ENGINEER
within 30 days after the date of such decision, and a formal proceeding is instituted by the appealing party in a
forum of competent jurisdiction within 60 days after the date of such decision or within 60 days after Substantial
Completion, whichever is later (unless otherwise agreed in writing by OWNER and CONTRACTOR), to exercise
such rights or remedies as the appealing party may have the respect to such Claim, dispute, or other matter in
accordance with applicable Laws and Regulations.

C. If ENGINEER does not render a formal decision in writing within the time stated in paragraph 10.05.B, a decision
denying the dispute in its entirety shall be deemed to have been issued 31 days after receipt of the last submittal of the
claimant or the submittal of the opposing party, if any.

D. No dispute for an adjustment in Contract Price or Contract Times (or Milestones) will be valid if not submitted in
accordance with this paragraph 10.05.

GC - 37 of 54