Finance Committee

17. City of Nashua, Standard Specifications for Road Construction, Approved and Adopted June 11,
1986, incorporated by reference.

18 City of Nashua, Standard Specifications for Sidewalk Construction, Approved and Adopted
August 28, 1995, incorporated by reference.

19 City of Nashua Ordinance O-03-219 (Amended), Approved November 14, 2003.
20 Fully Executed City of Nashua Purchase Order

B. The documents listed in paragraph 8.01.A are attached to this Agreement (except as expressly noted
otherwise above).

I CONTRACTOR has given ENGINEER written notice of all conflicts, errors, ambiguities or
discrepancies that CONTRACTOR has discovered in the Contract Documents, and the written resolution thereof by
ENGINEER is acceptable to CONTRACTOR.

J. The Contract Documents are generally sufficient to indicate and convey understanding of all terms and
conditions for performance and furnishing of the Work.

ARTICLE 8 - CONTRACT DOCUMENTS

8.01 Contents

A. The Contract Documents consist of the following:

specific cause for withholding additional retainage no further amount will be withheld. The
escrow account will remain at the same balance throughout the remainder of the project.

6.03 Final Payment

A. Upon final completion and acceptance of the Work in accordance with paragraph 14.07 of the General
Conditions, OWNER shall hold 2% retainage during the 1 (one) year warranty period and release it only after the
project has been accepted.

The Contract Sum shall include all items and services necessary for the proper execution and completion of the Work
determined below:

A. for all Unit Price Work, an amount equal to the sum of the established Unit Price for each separately
identified item of Unit Price Work times the estimated quantity of that
1tem, as indicated in the attached Bid Schedule;

STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND CONTRACTOR

THIS AGREEMENT is dated as of the day of in the year 2016 by and between the City of
Nashua, New Hampshire (hereinafter called OWNER) and DL King and Associates, Inc of 27 Tanglewood Drive

located in Nashua, New Hampshire and (its successors, transferees and assignees together hereinafter called
CONTRACTOR).

OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows:
ARTICLE 1 - WORK

DIVISION 5
AGREEMENT

IN WITNESS WHEREOF, this instrument is executed

in

which shall be deemed an original,
this

ATTEST:

By:

(Principal) Secretary

(SEAL)

By:

Witness as to Principal

(Address)

ATTEST:

By

Witness as to Surety

(Address)

counterparts, each one of
(number)

day of , 20

Principal
BY
(Address)
(Surety)
BY

Attorney - in - Fact

(Address)

PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.

CONSTRUCTION PAYMENT BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Address of Contractor)

a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.