City of Nashua
Purchasing Department
Administrative Services Division (603) 589-3330
229 Main Street - Nashua, NH 03060 Fax (603) 594-3233
November 22, 2021
Memo #22-192
TO: Mayor Donchess
Finance Committee
SUBJECT: Engineering Services for 2022 Sewer Rehab Program in the amount not to exceed
$229,500 funded from accounts 81700 Infrastructure Improvements
. ACORD® DATE paOONT)
CERTIFICATE OF LIABILITY INSURANCE
* Mc 5/3/2021
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS
CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES
BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED
REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER.
Le
THE CITY OF NASHUA
CONSTRUCTION OF A NEW D.P.W. ADMINISTRATION OFFICE BUILDING
CERTIFICATE OF INSURANCE
EXHIBIT “C”
5/03/2021
THE CITY OF NASHUA
CONSTRUCTION OF A NEW ADMINISTRION OFFICE BUILDING
HOURLY RATE SCHEDULE
EXHIBIT “B”
5/03/2021
Harvey Construction Corporation Rate Schedule Construction Management Services
Construction Personnel Rate
Certification of Document’s Authenticity
AIA® Document D401™ — 2003
I, William E. Stevens, President, hereby certify, to the best of my knowledge, information and belief, that I created the
attached final document simultaneously with its associated Additions and Deletions Report and this certification at
14:10:20 ET on 01/10/2020 under Order No. 1403731939 from AIA Contract Documents software and that in
i d final document I made no changes to the original text of AIA® Document A201™ — 2007,
ished by the AIA in its software, other than those
§ 15.4 ARBITRATION
§ 15.4.1 Intentionally omitted.
§ 15.4.1.1 Intentionally omitted.
§ 15.4.2 Intentionally omitted.
§ 15.4.3 Intentionally omitted.
§ 15.4.4 CONSOLIDATION OR JOINDER Intentionally omitted.
(Paragraphs deleted)
AIA Document A201™ - 2007, Copyright © 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1970, 1976, 1987, 1997 and 2007 by The American
init.
§ 15.1.2 NOTICE OF CLAIMS
Claims by either the Owner or Contractor must be initiated by written notice to the other party and to the Initial
Decision Maker with a copy sent to the Architect, if the Architect is not serving as the Initial Decision Maker.
§ 15.1.3 CONTINUING CONTRACT PERFORMANCE
§ 13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract
Documents, be secured by the Contractor and promptly delivered to the Architect.
§ 13.5.5 If the Architect is to observe tests, inspections or approvals required by the Contract Documents, the Architect
will do so promptly and, where practicable, at the normal place of testing.
§ 13.5.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid
unreasonable delay in the Work.
§ 12.3 ACCEPTANCE OF NONCONFORMING WORK
If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the
Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as
appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.
ARTICLE 13 MISCELLANEOUS PROVISIONS
§ 13.1 GOVERNING LAW
