If BIDDER is:
An Individual
Name (typed or printed): /
By: (SEAL)
inaividal 's Signature)
Doing business as:
Business address: /
l
Phone No.: / Fax No.:
/
A Partnership
Rid Farm
Partnership Name: / (SEAL)
Date and State of Organization
Names of Current General Partners
Name Title
Type of Partnership
(] General [(] Publicly Traded
(] Limited [(]} Other (describe):
By:
(Signature of “Te Partner — attach evidence of authority to sign)
801 The following documents are attached to and made a condition of this Bid:
A. Bid Form;
B. Bid Bond;
C. A tabulation of Subcontractors, Suppliers and other individuals and entities required to be
identified in this Bid; and
D. Construction Contractor's Qualification Statement.
9.01 Communications conceming this Bid shall be addressed to:
(Contractor's rel address ( o be filled in we Bidder)
Derel (Ow vpitn ov
28 Silva Lome
Dratwt Ma 01d 26
E. BIDDER does not consider that any further examinations, investigations, explorations,
tests, studies, or data are necessary for the determination of this Bid for performance of
the Work at the price(s) bid and within the times and in accordance with the other terms
and conditions of the Bidding Documents.
F. BIDDER is aware of the general nature of work to be performed by OWNER and others
at the Site that relates to the Work as indicated in the Bidding Documents.
BID FORM
PROJECT IDENTIFICATION: 2017 SEWER REPLACEMENT PROJECT
CONTRACT IDENTIFICATION AND NUMBER: IF'B07 79-041217
THIS BID IS SUBMITTED TO: City of Nashua
Purchasing Department
229 Main Street, City Hall
Nashua, NH 03061-2019
DIVISION 3
BID FORM
BID BOND
BID SCHEDULE
CONTRACTOR’S QUALIFICATIONS
23.02
23.03
23.04
E. Not seek any type of judicial intervention until Owner has rendered its final decision on
the protest.
Owner will stay award actions until after the Owner’s contract administrator has responded in
writing to the protest. If the appellant is not satisfied with the response, the appellant may then
protest to the Board of Public Works, who will render a final decision for the Owner. No bid
protests will be heard by the Board of Public Works unless bidder has followed the appeal
process.
19.04 In evaluating Bidders, OWNER will consider the qualifications of Bidders and may consider the
qualifications and experience of Subcontractors, Suppliers, and other individuals or entities
proposed for those portions of the Work for which the Subcontractors, Suppliers, and other
individuals or entities must be submitted as provided in the Supplementary Conditions..
15.02 A bid shall be submitted no later than the date and time prescribed and at the place indicated in
the advertisement or invitation to Bid and shall be enclosed in an opaque sealed envelope plainly
marked with the Project title (and, if applicable, the designated portion of the Project for which
the Bid is submitted), the name and address of Bidder, and shall be accompanied by the Bid
security and other required documents. If a Bid is sent by mail or other delivery system, the
13.04
13.05
13.06
13.07
13.08
13.09
13.10
13.11
A Bid by a partnership shall be executed in the partnership name and signed by a partner (whose
title must appear under the signature), accompanied by evidence of authority to sign. The
official address of the partnership must be shown below the signature.
ARTICLE10 LIQUIDATED DAMAGES
10.01 Provisions for liquidated damages, if any, are set forth in the Agreement.
ARTICLE 11 SUBSTITUTE AND “OR-EQUAL” ITEMS
