Search

17.

18.

19,

20.

Professional Engineer agrees to assist disadvantaged business enterprises in obtaining business
opportunities by identifying and encouraging disadvantaged suppliers, consultants, and sub
consultants to participate to the extent possible, consistent with their qualification, quality of work,
and obligation of Professional Engineer under this contract.

In connection with the performance of work under this contract, Professional Engineer agrees not
to discriminate against any employee or applicant for employment because of race, creed, color,
national origin, sex, age, or sexual orientation. This agreement includes, but is not limited to, the
following: employment, upgrading, demotion or transfer, recruitment or recruitment advertising,
layoff or termination, rates of pay or other forms of compensation, and selection for training,
including apprenticeship.

Professional Engineer agrees, if applicable, to insert these provisions in all subcontracts, except for
subcontracts for standard commercial supplies or raw materials. Any violation of any applicable
provision by Professional Engineer shall constitute a material breach of the contract.

ENDORSEMENT Professional Engineer shall seal and/or stamp and sign professional documents
including drawings, plans, maps, reports, specifications, and other instruments of service prepared
by Professional Engineer or under its direction as required under the laws of the State of New
Hampshire.

ASSIGNMENT, TRANSFER, DELEGATION, OR SUBCONTRACTING Professional Engineer shall not
assign, transfer, delegate, or subcontract any rights, obligations, or duties under this contract
without the prior written consent of the City of Nashua. Any such assignment, transfer, delegation,
or subcontracting without the prior written consent of the City of Nashua is void. Any consent of
the City of Nashua to any assignment, transfer, delegation, or subcontracting shall only apply to
the incidents expressed and provided for in the written consent and shall not be deemed to be a
consent to any subsequent assignment, transfer, delegation, or subcontracting. Any such
assignment, transfer, delegation, or subcontract shall require compliance with or shall incorporate
all terms and conditions set forth in this agreement, including all incorporated Exhibits and written
amendments or modifications. Subject to the foregoing provisions, the contract inures to the benefit
of, and is binding upon, the successors and assigns of the parties.

CITY INSPECTION OF CONTRACT MATERIALS The books, records, documents and accounting
procedures and practices of Professional Engineer related to this contract shall be subject to
inspection, examination and audit by the City of Nashua, including, but not limited to, the
contracting agency, Corporation Counsel, and, if applicable, the Comptroller General of the United
States, or any authorized representative of those entities.

DISPOSITION OF CONTRACT MATERIALS Any books, reports, studies, photographs, negatives or
other documents, data, drawings or other materials, including but not limited to those contained in
media of any sort (e.g., electronic, magnetic, digital) prepared by or supplied to Professional
Engineer in the performance of its obligations under this contract shall be the exclusive property of
the City of Nashua and all such materials shall be remitted and delivered, at Professional Engineer's
expense, by Professional Engineer to the City of Nashua upon completion, termination, or
cancellation of this contract. Alternatively, if the City of Nashua provides its written approval to
Professional Engineer, any books, reports, studies, photographs, negatives or other documents,
data, drawings or other materials including but not limited to those contained in media of any sort
(e.g., electronic, magnetic, digital) prepared by or supplied to Professional Engineer in the
performance of its obligations under this contract must be retained by Professional Engineer for a
minimum of four years after final payment is made and all other pending matters are closed. If, at
any time during the retention period, the City of Nashua, in writing, requests any or all of the
materials, then Professional Engineer shall promptly remit and deliver the materials, at Professional

GC 8 of Il

COMPETIT TALOG LISTINGS, IN-HOUSE ESTIMATES, PRIOR QUOTES MARKET | PROPOSED
(Indicate basis for price comparison) PRICE PRICE

INSERT THE APPROPRIATE WORK CATEGORY IN THE TABLE BELOW. WORK CATEGORIES WOULD
-INCLUDE BUT NOT BE LIMITED TO THOSE CATEGORIES SHOWN IN THE CONTRACT DOCUMENTS SUCH
AS DESIGN, SURVEY, SUBSURFACE, CADASTRAL, O&M MANUAL, ADMINISTRATION, INSPECTION,
RECORD DWGS., START-UP, SPECIAL SERVICES, ETC.

ork
category Task
—

Estimates | Average] Estimated
Hours Rate Cost

Bidding
Construct.
Admin.
Resident
Services
Start-up
Services
O&M
Manual
Drawings

Principal-in-Charge 8] $ 63.00 504.00

Project Manager 65] $ 58.00 3,770.00

n
ect Engineer

Lead Project Engineer 814] $ 43.00 35,002.00

10] $ 59.00 590.00

Project Engineer 764] $ 27.00 20,628.00

. ect nee -
Civil 58) $ 45.00 2,610.00

Sr. Project Architect 0) $ 41.00 -

r. neer -
Structural
ect Engineer -

Mechanical

r. neer -
Instrument.

r. neer -
Electrical

CADD Operator 116) $ 28.00 3,248.00

56| $ 56.00 3,136.00
0} $ 41.00 -
208| $ 58.00 12,064.00

184) $ 56.00 10,304.00

min. Assistant 116} $ 20.00 2,320.00

ect

tative 1,404 1,404] $ 27.00 37,908.00

1,910} 1,404] 202) 150) 137 3,803 -

132,084.00

comments:

Page 2 of 2

Pringipal-ine.

o Project:
2 Mariager’

vAdvisor/Sr,
Project:
“Engineer,

TABLE B-1. SUMMARY OF ESTIMATED STAFF EFFORT (HOURS) AND COSTS BY TASK FOR HOME OFFICE SERVICES
CONSTRUCTION PHASE SERVICES FOR THE NASHUA WASTEWATER PUMP STATION UPGRADES PROJECT
NASHUA, NH

‘Sr. Preject : Project Srv: Project Sr. Project “
Engineer ~ Sr.-Project: -: Engineer « Engineer + Engineer | -CADD
Civil Architect Mechanical Instrument: Operator

Admin.
Assistant.

Direct Labor
Indirect Labor
Non-Labor
Subcontractor
Sub Markup
Fixed Fea
Total Fee

SUBS

DIRECT
LABOR:COST

$94,176
$158,187
$7,400

$0

$0

$26,236
$285,000.00

TOTAL

TABLE B-2. SUMMARY OF ESTIMATED STAFF EFFORT (HOURS) AND COSTS BY TASK FOR FIELD OFFICE SERVICES
CONSTRUCTION PHASE SERVICES FOR THE NASHUA WASTEWATER PUMP STATION UPGRADES PROJECT

NASHUA, NH
Resident | ; a
y : ° Project gene Admin : we : = DIRECT [0
_ = TASK DESCRIPTIONS... | Representative} Assistant RPR|' Assistant {TOTAL HOURS| NON-LABOR. | SUBS LABOR COST).
“0 Labor Billing Ratel "$27.00 ee oes Conf . cpeoe ee
2B Resident Services 1404 0 0 1404 $13,160 $0 $37,908 [13.5 Months, 3 diwk, 8.0 hrs/d on avg
TOTAL HOURS 1404 0 0 1404 $13,160 $0 $37,908
’ TASK 2B Direct Labor $37,908.00
Indirect Labor $63,674.07
Non-Labor $13,159.73
Subcontractor $0.00
Sub mark-up $0.00
Fixed fee $10,158
Total Fee $124,900.00

Exhibit A

. FEDERAL and STATE
REPORTING REQUIREMENTS

Preparation of application, supporting and associated documents for Federal, State, and other grant or
loan programs, including monthly reimbursement requests. Federal and State requirements to be handled
by the ENGINEER include:

Davis Bacon Weekly Contractor Log, which is a record of which contractors and
subcontractors are on site each week;

Receipt and review of Certified Payrolls;

Davis Bacon Interviews;

Collection of MBE/WBE information from the CONTRACTOR for OWNER’S’s annual
reporting to DES of MBE/WBE Utilization;

Monitoring the AIS De Minimis Waiver list on behalf of the OWNER;
Participation in DES on-site Davis Bacon and AIS reviews;

Collection of AIS manufacturer certifications, for all submittals that include American
Tron and Steel items;

Collection monthly of Davis Bacon and American Iron and Steel Certifications and
collecting de minimis list form and backup documentation (invoices) for OWNER’S
project records, from the CONTRACTOR, for attachment to CONTRACTOR’s monthly
payment application effort;

IA Ye FY

co

10.
11.
12.

14.
15.
16.
17.
18.
19.
20,
21.
22.
23.
24.
25.
26.

28.
29,
30.
31.

EXHIBIT B

CITY OF NASHUA
PROFESSIONAL SERVICES
GENERAL TERMS and CONDITIONS

DEFINITIONS

PROFESSIONAL ENGINEER STATUS
STANDARD OF CARE

CITY OF NASHUA REPRESENTATIVE
CHANGES TO SCOPE OF WORK
Ciry OF NASHUA COOPERATION

DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR
DISCREPANCIES

TERMINATION OF CONTRACT

DISPUTE RESOLUTION

NO DAMAGES FOR DELAY

INSURANCE

INDEMNIFICATION

FISCAL CONTINGENCY

COMPENSATION

COMPLIANCE WITH APPLICABLE LAWS
NONDISCRIMINATION

ENDORSEMENT

ASSIGNMENTS, TRANSFER, DELEGATION, OR SUBCONTRACTING
CITY INSPECTION OF CONTRACT MATERIALS
DISPOSITION OF CONTRACT MATERIALS

PUBLIC RECORDS LAW, COPYRIGHTS, AND PATENTS
FINAL ACCEPTANCE

TAXES

NON-WAIVER OF TERMS AND CONDITIONS

RIGHTS AND REMEDIES

PROHIBITED INTERESTS

THIRD PARTY INTERESTS AND LIABILITIES
SURVIVAL OF RIGHTS AND OBLIGATIONS
SEVERABILITY

MODIFICATION OF CONTRACT AND ENTIRE AGREEMENT

CHOICE OF LAW AND VENUE

GC lof il

GC--2
GC--2
GC--2
GC--3
GC--3
GC--3

GC--3
GC--4
GC--5
GC--6
GC--6
GC--7
GC--7
GC--7
GC--7
GC--8
GC--8
GC--8
GC--9
GC--9
GC--9
GC--10
GC--10
GC--10
GC--10
GC--10
GC--11
GC--11
GC--11
GC--11
GC--11

1,

General Terms and Conditions

DEFINITIONS Unless otherwise required by the context, "Professional Engineer”, and its
successors, transferees and assignees (together “Professional Engineer”) includes any of the
Professional Engineer's consultants, sub consultants, contractors, and subcontractors

PROFESSIONAL ENGINEER STATUS The parties agree that Professional Engineer shall have the
status of and shall perform all work under this contract as a Professional Engineer, maintaining
control over all its consultants, sub consultants, contractors, or subcontractors. The only
contractual relationship created by this contract is between the City of Nashua and Professional
Engineer, and nothing in this contract shall create any contractual relationship between the City
of Nashua and Professional Engineer's consultants, sub consultants, contractors, or
subcontractors. The parties also agree that Professional Engineer is not a City of Nashua
employee and that there shall be no:

(1) Withholding of income taxes by the City of Nashua:

(2) Industrial insurance coverage provided by the City of Nashua;

(3) Participation in group insurance plans which may be available to employees of
the City of Nashua;

(4) Participation or contributions by either the Professional Engineer or the City of
Nashua to the public employee’s retirement system;

(5) Accumulation of vacation leave or sick leave provided by the City of Nashua;

(6) Unemployment compensation coverage provided by the City of Nashua.

STANDARD OF CARE Professional Engineer shall be responsible for the professional quality,
technical accuracy, timely completion, and coordination of all work performed under this
contract. Professional Engineer warrants that all work shall be performed with the degree of
professional skill, care, diligence, and sound practices and judgment that are normally exercised
by recognized professional firms with respect to services of a similar nature. It shall be the duty
of Professional Engineer to assure at its own expense that all work is technically sound and in
conformance with all applicable federal, state, and local laws, statutes, regulations, ordinances,
orders, or other requirements. In addition to all other rights which the City of Nashua may have,
Professional Engineer shall, at its own expense and without additional compensation, re-perform
work to correct or revise any deficiencies, omissions, or errors in the work or the product of the
work or which result from Professional Engineer's failure to perform in accordance with this
standard of care. Any approval by the City of Nashua of any products or services furnished or
used by Professional Engineer shall not in any way relieve Professional Engineer of the
responsibility for professional and technical accuracy and adequacy of its work. City of Nashua
review, approval, or acceptance of, or payment for any of Professional Engineer's work under this
contract shall not operate as a waiver of any of the City of Nashua's rights or causes of action
under this contract, and Professional Engineer shall be and remain liable in accordance with the
terms of the contract and applicable law.

Professional Engineer shall furnish competent and skilled personnel to perform the work under
this contract. The City of Nashua reserves the right to approve key personnel assigned by
Professional Engineer to perform work under this contract. Approved key personnel shall not be
taken off of the project by Professional Engineer without the prior written approval of the City of
Nashua, except in the event of termination of employment. Professional Engineer shall, if
requested to do so by the City of Nashua, remove from the job any personnel whom the City of
Nashua determines to be incompetent, dishonest, or uncooperative.

GC 2 of 11

4. Ciry OF NASHUA REPRESENTATIVE The City of Nashua may designate a City of Nashua
representative for this contract. If designated, all notices, project materials, requests by
Professional Engineer, and any other communication about the contract shall be addressed or be
delivered to the City of Nashua Representative.

5. CHANGES TO SCOPE OF WORK The City of Nashua may, at any time, by written order, make
changes to the general scope, character, or cost of this contract and in the services or work to be
performed, either increasing or decreasing the scope, character, or cost of Professional Engineer's
performance under the contract. Professional Engineer shall provide to the City of Nashua within
10 calendar days, a written proposal for accomplishing the change. The proposal for a change
shall provide enough detail, including personnel hours for each sub-task and cost breakdowns of
tasks, for the City of Nashua to be able to adequately analyze the proposal. The City of Nashua
will then determine in writing if Professional Engineer should proceed with any or all of the
proposed change. If the change causes an increase or a decrease in Professional Engineer's cost
or time required for performance of the contract as a whole, an equitable adjustment shall be
made and the contract accordingly modified in writing. Any claim of Professional Engineer for
adjustment under this clause shall be asserted in writing within 30 days of the date the City of
Nashua notified Professional Engineer of the change.

When Professional Engineer seeks changes, Professional Engineer shall, before any work
commences, estimate their effect on the cost of the contract and on its schedule and notify the
City of Nashua in writing of the estimate. The proposal for a change shall provide enough detail,
including personnel hours for each sub-task and cost breakdowns of tasks, for the City of Nashua
to be able to adequately analyze the proposal. The City of Nashua will then determine in writing
if Professional Engineer should proceed with any or all of the proposed change.

Except as provided in this paragraph, Professional Engineer shall implement no change unless the
City of Nashua in writing approves the change. Unless otherwise agreed to in writing, the
provisions of this contract shall apply to all changes. The City of Nashua may provide verbal
approval of a change when the City of Nashua, in its sole discretion, determines that time is
critical or public health and safety are of concern. Any verbal approval shall be confirmed in
writing as soon as practicable. Any change undertaken without prior City of Nashua approval
shall not be compensated and is, at the City of Nashua's election, sufficient reason for contract
termination.

6. CITY OF NASHUA COOPERATION The City of Nashua agrees that its personnel will cooperate
with Professional Engineer in the performance of its work under this contract and that such
personnel will be available to Professional Engineer for consultation at reasonable times and after
being given sufficient advance notice that will prevent conflict with their other responsibilities.
The City of Nashua also agrees to provide Professional Engineer with access to City of Nashua
records in a reasonable time and manner and to schedule items that require action by the Board of
Public Works and Finance Committee in a timely manner. The City of Nashua and Professional
Engineer also agree to attend all meetings called by the City of Nashua or Professional Engineer
to discuss the work under the Contract, and that Professional Engineer may elect to conduct and
record such meetings and shall later distribute prepared minutes of the meeting to the City of
Nashua.

7. DISCOVERY OF CONFLICTS, ERRORS, OMISSIONS, AMBIGUITIES, OR DISCREPANCIES
Professional Engineer warrants that it has examined all contract documents, has brought all
conflicts, errors, discrepancies, and ambiguities to the attention of the City of Nashua in writing,
and has concluded that the City of Nashua's resolution of each matter is satisfactory to
Professional Engineer. All future questions Professional Engineer may have concerning
interpretation or clarification of this contract shall be submitted in writing to the City of Nashua
within 10 calendar days of their arising. The writing shall state clearly and in full detail the basis
for Professional Engineer's question or position. The City of Nashua representative shall render a

GC 3 of 11

decision within 15 calendar days. The City of Nashua's decision on the matter is final. Any work
affected by a conflict, error, omission, or discrepancy which has been performed by Professional
Engineer prior to having received the City of Nashua's resolution shall be at Professional
Engineer's risk and expense. At all times, Professional Engineer shall carry on the work under
this contract and maintain and complete work in accordance with the requirements of the contract
or determination of the City of Nashua. Professional Engineer is responsible for requesting
clarification or interpretation and is solely liable for any cost or expense arising from its failure to
do so.

TERMINATION OF CONTRACT

A. TERMINATION, ABANDONMENT, OR SUSPENSION AT WILL. The City of Nashua, in its sole
discretion, shall have the right to terminate, abandon, or suspend all or part of the project and
contract at will. If the City of Nashua chooses to terminate, abandon, or suspend all or part of the
project, it shall provide Professional Engineer 10 day’s written notice of its intent to do so.

If all or part of the project is suspended for more than 90 days, the suspension shall be treated as a
termination at will of all or part of the project and contract.

Upon receipt of notice of termination, abandonment, or suspension at will, Professional Engineer
shall:

Immediately discontinue work on the date and to the extent specified in the notice.

Place no further orders or subcontracts for materials, services, or facilities, other than as

may be necessary or required for completion of such portion of work under the contract

that is not terminated.

3. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or subcontracts to the extent they relate
to the performance of work terminated, abandoned, or suspended under the notice,
assign to the City of Nashua any orders or subcontracts specified in the notice, and
revoke agreements specified in the notice.

4. Not resume work after the effective date of a notice of suspension until receipt of a

written notice from the City of Nashua to resume performance.

Ne

In the event of a termination, abandonment, or suspension at will, Professional Engineer shall
receive all amounts due and not previously paid to Professional Engineer for work satisfactorily
completed in accordance with the contract prior to the date of the notice and compensation for
work thereafter completed as specified in the notice. No amount shall be allowed or paid for
anticipated profit on unperformed services or other unperformed work.

B. TERMINATION FOR CAUSE This agreement may be terminated by the City of Nashua on 10
calendar day’s written notice to Professional Engineer in the event of a failure by Professional
Engineer to adhere to any or all the terms and conditions of the contract or for failure to
satisfactorily, in the sole opinion of the City of Nashua, to complete or make sufficient progress
on the work in a timely and professional manner. Professional Engineer shall be given an
opportunity for consultation with the City of Nashua prior to the effective date of the termination.
Professional Engineer may terminate the contract on 10 calendar days written notice if, through
no fault of Professional Engineer, the City of Nashua fails to pay Professional Engineer for 45
days after the date of approval by the City of Nashua of any Application for Payment.

Upon receipt of notice of termination for cause, Professional Engineer shall:

1. Immediately discontinue work on the date and to the extent specified in the notice.
2. Provide the City of Nashua with a list of all unperformed services.

GC 4 of 11

a

Place no further orders or sub-contracts for materials, services, or facilities, other than
as may be necessary or required for completion of such portion of work under the
contract that is not terminated.

4. Immediately make every reasonable effort to obtain cancellation upon terms
satisfactory to the City of Nashua of all orders or sub contracts to the extent they relate
to the performance of work terminated, abandoned, or suspended under the notice,
assign to the City of Nashua any orders or sub contracts specified in the notice, and
revoke agreements specified in the notice.

5. Not resume work after the effective date of a notice of termination unless and until

receipt of a written notice from the City of Nashua to resume performance.

In the event of a termination for cause, Professional Engineer shall receive all amounts due and
not previously paid to Professional Engineer for work satisfactorily completed in accordance with
the contract prior to the date of the notice, less all previous payments. No amount shall be
allowed or paid for anticipated profit on unperformed services or other unperformed work. Any
such payment may be adjusted to the extent of any additional costs occasioned to the City of
Nashua by reasons of Professional Engineer's failure. Professional Engineer shall not be relieved
of liability to the City of Nashua for damages sustained from the failure, and the City of Nashua
may withhold any payment to the Professional Engineer until such time as the exact amount of
damages due to the City of Nashua is determined. All claims for payment by the Professional
Engineer must be submitted to the City of Nashua within 30 days of the effective date of the
notice of termination.

If after termination for the failure of Professional Engineer to adhere to any of the terms and
conditions of the contract or for failure to satisfactorily, in the sole opinion of the City of Nashua,
to complete or make sufficient progress on the work in a timely and professional manner, it is
determined that Professional Engineer had not so failed, the termination shall be deemed to have
been a termination at will. In that event, the City of Nashua shall, if necessary, make an
adjustment in the compensation paid to Professional Engineer such that Professional. Engineer
receives total compensation in the same amount as it would have received in the event of a
termination-at-will.

C. GENERAL PROVISIONS FOR TERMINATION Upon termination of the contract, the City of
Nashua may take over the work and prosecute it to completion by agreement with another party
or otherwise. In the event Professional Engineer shall cease conducting business, the City of
Nashua shall have the right to solicit applications for employment from any employee of the
Professional Engineer assigned to the performance of the contract.

Neither party shall be considered in default of the performance of its obligations hereunder to the
extent that performance of such obligations is prevented or delayed by any cause, existing or
future, which is beyond the reasonable control of such party. Delays arising from the actions or
inactions of one or more of Professional Engineer's principals, officers, employees, agents,
subcontractors, consultants, vendors, or suppliers are expressly recognized to be within
Professional Engineer's control.

DISPUTE RESOLUTION The parties shall attempt to resolve any dispute related to this contract
as follows. Either party shall provide to the other party, in writing and with full documentation to
verify and substantiate its decision, its stated position concerning the dispute. No dispute shall be
considered submitted and no dispute shall be valid under this provision unless and until the ~
submitting party has delivered the written statement of its position and full documentation to the
other party. The parties shall then attempt to resolve the dispute through good faith efforts and
negotiation between the City of Nashua Representative and a Professional Engineer
Representative. At all times, Professional Engineer shall carry on the work under this contract
and maintain and complete work in accordance with the requirements of the contract or
determination or direction of the City of Nashua. If the parties are unable to resolve their dispute
as described above within 30 days, the parties may request that the dispute be submitted to the

GC 5 of il