Finance Committee

Certification of Document’s Authenticity
AIA® Document D401™ — 2003

I, William E. Stevens, President, hereby certify, to the best of my knowledge, information and belief, that I created the
attached final document simultaneously with its associated Additions and Deletions Report and this certification at
14:10:20 ET on 01/10/2020 under Order No. 1403731939 from AIA Contract Documents software and that in

i d final document I made no changes to the original text of AIA® Document A201™ — 2007,
ished by the AIA in its software, other than those

§ 15.4 ARBITRATION
§ 15.4.1 Intentionally omitted.
§ 15.4.1.1 Intentionally omitted.

§ 15.4.2 Intentionally omitted.
§ 15.4.3 Intentionally omitted.

§ 15.4.4 CONSOLIDATION OR JOINDER Intentionally omitted.

(Paragraphs deleted)

AIA Document A201™ - 2007, Copyright © 1911, 1915, 1918, 1925, 1937, 1951, 1958, 1961, 1963, 1966, 1970, 1976, 1987, 1997 and 2007 by The American

init.

§ 15.1.2 NOTICE OF CLAIMS
Claims by either the Owner or Contractor must be initiated by written notice to the other party and to the Initial
Decision Maker with a copy sent to the Architect, if the Architect is not serving as the Initial Decision Maker.

§ 15.1.3 CONTINUING CONTRACT PERFORMANCE

Init.

§ 13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract
Documents, be secured by the Contractor and promptly delivered to the Architect.

§ 13.5.5 If the Architect is to observe tests, inspections or approvals required by the Contract Documents, the Architect
will do so promptly and, where practicable, at the normal place of testing.

§ 13.5.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid
unreasonable delay in the Work.

§ 12.3 ACCEPTANCE OF NONCONFORMING WORK

If the Owner prefers to accept Work that is not in accordance with the requirements of the Contract Documents, the
Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as
appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made.

ARTICLE 13 MISCELLANEOUS PROVISIONS

§ 13.1 GOVERNING LAW

ARTICLE 12. UNCOVERING AND CORRECTION OF WORK

§ 12.1 UNCOVERING OF WORK

§ 12.1.4 Ifa portion of the Work is covered contrary to the Architect’s request or to requirements specifically expressed
in the Contract Documents, it must, if requested in writing by the Architect, be uncovered for the Architect's
examination and be replaced at the Contractor’s expense without change in the Contract Time.

applicable legal requirements, and shall cover reasonable compensation for Architect’s and Contractor’s services and
expenses required as a result of such insured loss.

(Paragraphs deleted)
§ 11.3.1.4 This property insurance shall cover portions of the Work stored off the site, and also portions of the Work in
transit. The insurance shall include a permission to occupy endorsement.

Init.

None of the requirements as to types and limits to be maintained by Contractor are intended to and shall not in any
manner limit or qualify the liabilities and obligations assumed by Contractor under this contract. The Owgner shall
not maintain any insurance on behalf of Contractor. Subcontractors are subject to the same insurance requirements as
Contractor and it shall be the Contractor’s responsibility to ensure compliance of this requirement.

Init.

§ 10.4 EMERGENCIES

In an emergency affecting safety of persons or property, the Contractor shall act, at the Contractor’s discretion, to
prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on
account of an emergency shall be determined as provided in Article 15 and Article 7.