Agenda

DIVISION 5
AGREEMENT

IN WITNESS WHEREOF, this instrument is executed

in

which shall be deemed an original,
this

ATTEST:

By:

(Principal) Secretary

(SEAL)

By:

Witness as to Principal

(Address)

ATTEST:

By

Witness as to Surety

(Address)

counterparts, each one of
(number)

day of , 20

Principal
BY
(Address)
(Surety)
BY

Attorney - in - Fact

(Address)

PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.

CONSTRUCTION PAYMENT BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Address of Contractor)

a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.

CONSTRUCTION PERFORMANCE BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Addtess of Contractor)

a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

hereinafter called OWNER, in the total aggregate penal sum
of

Dollars, $
/ )

DIVISION 4

PERFORMANCE
AND

PAYMENT BONDS

Schedule C_- Construction Experience of Principal Individuals Involved in Construction Operations

Name

A. Dean King

Position

Vice President

William Pritchard Project Manager

Arthue E. King,

Curt Spencer

uUr.P.Es CFO

Civil Engineer

Date started with
this organization

1999

2010
1999

2013

CQ -7 of 7

Date started
working in
construction

1990

1980
L365

2013

Prior positions and experience in
construction

D.L. KING & ASSOCIATES, INC.

Schedule B - List of Current Projects Under Construction

Schedule_A — List of Major Engineered Construction Projects Completed in the Past Five (5) Years

Name, Location and