NOTICE TO PROCEED
DATED:
TO: Fimbel Paunet dba Fimbel Garage Doors
(Contractor}
ADDRESS: 281 Daniel Webster Highway
PROJECT: DPW Street Department Garage Doors Replacement
(Insert name of Contract as it appears in the Contract Agreement)
You are notified that the Contract Times under the above contract will commence to run on
INSERT CERTIFICATE OF LIABILITY INSURANCE
IN WITNESS WHEREOF, this instrument is executed
in
which shall be deemed an original,
this
ATTEST:
By:
counterparts, each one of
(number)
day of , 20
(Principal) Secretary
(SEAL)
By:
Witness as to Principal
(Address)
ATTEST:
By
Witness as to Surety
(Address)
Principal
BY
(Address)
(Surety)
BY
Attorney - in - Fact
(Address)
PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.
CONSTRUCTION PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.
CONSTRUCTION PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
hereinafter called OWNER, in the total aggregate penal sum
of
Dollars, $
/ )
NOTICE OF AWARD
DATED:
TO: Fimbel Paunet dba Fimbel Garage Doors
(Contractor)
ADDRESS: 281 Daniel Webster Highway
PROJECT: DPW Street Department Garage Doors Replacement
(Insert name of Contract as it appears in the Contract Agreement)
You are notified that a Contract Award has been approved for execution for the following project:
Replacement of five (5) garage bay doors at the City of Nashua’s Division of Public Works (DPW) Street
I f M B E L Fimbel Garage Doors
GARAGE DOORS
THE GARAGE DOOR EXPERTS™ 800-556-9786
United States
Billing Address
City of Nashua, c/o Purchasing
PO Box 2019
Nashua, NH 03061-2019 USA
Estimate Details
281 Daniel Webster Hwy, Merrimack, NH 03054
Estimate 50134999
Job 50147554
Estimate Date 10/27/2021
Customer PO
Job Address
Nashua DPW
9 Stadium Drive
Nashua, NH 03062 USA
e Gate City
Addendum 1
IFB 0285-110221
Questions and Answers
Question Answer
1. | | was reaching out to see if there is any estimate value/start date The Plan Holder’s list is available on the City’s website
and Plan Holder’s List available? https://www.nashuanh.gov/bids.aspx?bidID=341. The project is
estimated to be awarded in December.
