EXHIBIT E
NOTICE TO PROCEED
DATED:
TO:
(Independent Contractor)
ADDRESS:
PROJECT:
(Insert name of Contract)
You are notified that the Contract Times under the above contract will commence to run on
, 20 . By that date, you are to start performing your obligations under the
Contract Documents, in accordance with the terms of the Agreement.
Also before you may start any Work at the site you must:
y
1 of 1
Notice to Proceed
PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.
EXHIBIT D-2
CONSTRUCTION PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
hereinafter called OWNER, in the total aggregate penal’s
copy of which is hereto atta:.,»ed ax:d made a part hereof for the construction of:
IN WITNESS WHEREOF, this instrument is executed
in counterparts, each one of
(number)
which shall be deemed an original,
this day of , 20
ATTEST:
Principal
By:
(Principal) Secretary
(SEAL) BY
(Address)
By:
Witness as to Principal
(Address)
(Surety)
ATTEST:
Attorney - in - Fact
By
Witness as to Surety (Address)
(Address 5
NOTE: Date of BOND mus sotdle prior to date of Contract.
If CONTRACTOR is partner: ip, all partners should execute BOND.
PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.
EXHIBIT D-1
CONSTRUCTION PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
hereinafter called OWNER and unto all persons, firms
labor, or who furnish materials to perform as described
EXHIBIT C
NOTICE OF AWARD
DATED:
TO:
(Independent Contractor)
ADDRESS:
PROJECT:
(Insert name of Contract)
The Contract Price of your contract is
The proposed Contract that the City of Nashua expects to execute, é
1. You must deliver to the City of Nashua fully #liecuted co
that the City of Nashua expects to execute; a
4
ty (Bonds), as specified in the General
f Liability Insurance, as specified in General
Conditions, Section 11- Insurance.
3. (List other conditions precedents)
EXHIBIT B
Client: City of Nashua, NH Artisan Skateparks
Signature Signature
Printed Name Printed Name
Date Date
J
Ces,
gs
Artisan Skateparks
4600 Tamarack Dr., Kitty Hawk, NC, 27949
Andy Duck (252)202-1333, Fax (252)261-1184
artisanskateparks.com
EXHIBIT B
Cost of any fencing, lighting, electrical or other amenities is not included in the fee
above.
Contract Provisions
1.
The compensation due Artisan Skateparks for the work to be performed hereunder shall be
set forth in Fees and Expenses above. The parties understand and agree that all work not
specifically delineated within the scope of work described herein shall be billed on a time
and materials basis, and shall be in addition to any budget, bid, or maximum price
agreement for the above described scope of work.
EXHIBIT B
These services are potential and will or can be negotiated throughout the project:
Earthwork (import, compaction, stormwater drainage, and rough grading)
Irrigation (trenching)
Gravel Subbase
Material Donations (lumber, screws, concrete, rebar, steel, sand, stone)
Mobilization Expenses (housing, temporary storage container, dumpster services, portable
restrooms)
