Finance Committee

If BIDDER is:

An Individual

A Partnership

Bid Form

Name (typed or printed):

By: (SEAL)
(Individual’s Signature)
Doing business as:

Business address:

Phone No.: Fax No.:

Partnership Name: Charter Contracting Company, LLC

Date and State of Organization
October 29, 2014

Massachusetts

Names of Current General Partners

Name Title
Robert L. Delhome, President Lou Schena, Chief Operations Officer

Anthony J. Pisanelli, Vice President Michael N. Bissonnette, Vice President

8.01 The following documents are attached to and made a condition of this Bid:

A. Bid Form;

B. Bid Bond;

C. A tabulation of Subcontractors, Suppliers and other individuals and entities required to be
identified in this Bid; and

D. Construction Contractor's Qualification Statement.

9.01 Communications concerning this Bid shall be addressed to:
(Contractor's mailing address to be filled in by Bidder)

Charter Contracting Company, LLC
Attention: Rick Abelard

500 Harrison Avenue, Suite 4R

Boston, MA 02118

E. BIDDER does not consider that any further examinations, investigations, explorations,
tests, studies, or data are necessary for the determination of this Bid for performance of
the Work at the price(s) bid and within the times and in accordance with the other terms
and conditions of the Bidding Documents.

F. BIDDER is aware of the general nature of work to be performed by OWNER and others
at the Site that relates to the Work as indicated in the Bidding Documents.

BID FORM

PROJECT IDENTIFICATION:_Spring 2017 Landfill Gas System Expansion
CONTRACT IDENTIFICATION AND NUMBER: IFB0593-113016

THIS BID IS SUBMITTED TO: City of Nashua
Purchasing Department
229 Main Street, City Hall
Nashua, NH 03061-2019

DIVISION 3

BID FORM
BID BOND
CONTRACTOR’S QUALIFICATIONS

ARTICLE 22 RETAINAGE

22.01 Provisions concerning retainage and Contractors’ rights to deposit securities in lieu of retainage
are set forth in the Agreement.

ARTICLE23. APPEAL BY BIDDERS

23.01 Any bidder may appeal a pending bid award prior to award by Owner. The appellant must:

A. Submit a written protest to the Owner’s contract administrator within five (5) workdays
after the bid opening.

B. Describe, in the written protest, the issues to be addresses on appeal.

ARTICLE 19 AWARD OF CONTRACT

14.02 The Bid price shall include such amounts as the Bidder deems proper for overhead and profit on
account of cash allowance, if any, named in the Contract Documents as provided in paragraph
11.02 of the General Conditions.

ARTICLE15 SUBMITTAL OF BID

15.01 Each prospective Bidder is furnished one copy of the Bidding Documents with one separate
unbound copy each of the Bid Form, and if required, the Bid Bond. The unbound copy of the
Bid Form is to be completed and submitted with the Bid security and the following data:

ARTICLE 13 PREPARATION OF BID

13.01

13.02

13.03

13.04

13.05

13.06

13.07

13.08

13.09

13.10

13.11

The Bid Form is included with the Bidding Documents.

All blanks on the Bid Form and Bid Schedule(s) must be completed by printing in ink or typed
and the Bid signed. A bid price shall be indicated for each Bid item listed therein.

8.03 Bid security of other Bidders whom OWNER believes do not have a reasonable chance of
receiving the award will be retumed within seven days after the Bid opening.

ARTICLE 9 CONTRACT TIMES

9.01 The number of calendar days within which, or the dates by which, the Work is to be (a)
substantially completed and (b) also completed and ready for final payment are set forth in the
Agreement.

ARTICLE10 LIQUIDATED DAMAGES

10.01 Provisions for liquidated damages, if any, are set forth in the Agreement.