ARTICLE 6 - PAYMENT PROCEDURES
6.01 Submittal and Processing of Payments
A. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the
General Conditions. Applications for Payment will be processed by ENGINEER as provided in the
General Conditions.
B. Application for Payment performed under this agreement shall be submitted as follows:
> Electronically via email to VendorAPInvoices@NashuaNH.gov
OR
4.02 Dates for Substantial Completion and Final Payment
Project will begin once a written “Notice to Proceed” is issued.
Substantial Completion shall be 180 __ calendar days from the Notice to Proceed and Final
Completion shall be __240 _ calendar days from the Notice to Proceed
4.03 Liquidated Damages
STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND CONTRACTOR
THIS AGREEMENT is dated as of the day of in the year 2022 by and between
the City of Nashua, New Hampshire (hereinafter called OWNER) and
and its successors, transferees and assignees together hereinafter called CONTRACTOR).
OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as
follows:
ARTICLE 1 - WORK
1.01 CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents.
ARTICLE 2 - THE PROJECT
DIVISION 3
0779-021022
2022 SEWER REPLACEMENT PROJECT
> CONTRACT AGREEMENT
INSERT CERTIFICATE OF LIABILITY INSURANCE
COI-1
PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.
CONSTRUCTION PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
hereinafter called OWNER, in the total aggregate penal sum
of
Dollars, $ ( )
IN WITNESS WHEREOF, this instrument is executed
in
which shall be deemed an original,
this
ATTEST:
By:
counterparts, each one of
(number)
day of , 20
(Principal) Secretary
(SEAL)
By:
Witness as to Principal
(Address)
ATTEST:
By
Witness as to Surety
(Address)
Principal
BY
(Address)
(Surety)
BY
Attorney - in - Fact
(Address)
PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.
CONSTRUCTION PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
