Agenda

B-6.1

CHANGE ORDER

This page intentionally left blank

Notice to Proceed

B-5.1

NOTICE TO PROCEED
DATED:

TO:

(Contractor)
ADDRESS:
OWNER’ S CONTRACT NO. : IFB1094-100217
PROJECT: Wastewater Treatment Facility SCADA System Upgrades

(Insert name of Contract as it appears in the Bidding Document)

You are notified that the Contract Times under the above contract will commence to run on
,20___. By that date, you are to start performing your obligations under the Contract

B-4.2

PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.

B-4.1

PERFORMANCE BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

hereinafter called OWNER, in the total aggregate penal sum
of

Dollars, $

;—_____)

This page intentionally left blank

IN WITNESS WHEREOF, this instrument is executed

in

which shall be deemed an original,
this

ATTEST:

By:

(Principal) Secretary

(SEAL)

By:

Witness as to Principal

(Address)

ATTEST:

By

Witness as to Surety

(Address)

B-3.3

counterparts, each one of
(number)

day of , 20

Principal
BY
(Address)
(Surety)
BY

Attorney - in - Fact

(Address)

B-3.2

PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.

B-3.1

PAYMENT BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

This page intentionally left blank