B-5.1
NOTICE TO PROCEED
DATED:
TO:
(Contractor)
ADDRESS:
OWNER’ S CONTRACT NO. : IFB1094-100217
PROJECT: Wastewater Treatment Facility SCADA System Upgrades
(Insert name of Contract as it appears in the Bidding Document)
You are notified that the Contract Times under the above contract will commence to run on
,20___. By that date, you are to start performing your obligations under the Contract
B-4.2
PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.
B-4.1
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
(Address of Owner)
hereinafter called OWNER, in the total aggregate penal sum
of
Dollars, $
;—_____)
This page intentionally left blank
IN WITNESS WHEREOF, this instrument is executed
in
which shall be deemed an original,
this
ATTEST:
By:
(Principal) Secretary
(SEAL)
By:
Witness as to Principal
(Address)
ATTEST:
By
Witness as to Surety
(Address)
B-3.3
counterparts, each one of
(number)
day of , 20
Principal
BY
(Address)
(Surety)
BY
Attorney - in - Fact
(Address)
B-3.2
PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.
B-3.1
PAYMENT BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Name of Contractor)
(Address of Contractor)
a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)
hereinafter called Surety, are held and firmly bound unto
(Name of Owner)
This page intentionally left blank
B-2.3
IN WITNESS WHEREOF, the parties hereto have executed, or caused to be executed by their
duly authorized officials, this Agreement in_5 copies, each of which shall be deemed an
original on the date first above written.
CITY OF NASHUA —- OWNER
James Donchess, Mayor City of Nashua
Date:
(SEAL)
ATTEST:
Name:
Title:
CONTRACTOR:
By:
(Authorized Representative)
Print Name:
Date:
(SEAL)
ATTEST:
Name:
Title:
B-2.2
5. The term "CONTRACT DOCUMENTS" means and includes the following:
(A)
(B)
(C)
(D)
(E)
(F)
(G)
(H)
(1)
(J)
(K)
(L)
(M)
(N)
(O)
(P)
(Q)
(R)
(S)
(T)
(U)
(V)
ADVERTISEMENT FOR BIDS
INFORMATION FOR BIDDERS
BID
BID BOND
NOTICE OF AWARD
AGREEMENT
PAYMENT BOND
PERFORMANCE BOND
CERTIFICATE OF INSURANCE
NOTICE TO PROCEED
CHANGE ORDER(S)
