Agenda

CONTRACTOR is entitled to rely upon the general accuracy of the “technical data” as provided in paragraph 4.2 of the
General Conditions. CONTRACTOR acknowledges that such reports and drawings are not Contract Documents and
may not be complete for CONTRACTOR's purposes. CONTRACTOR acknowledges that OWNER and ENGINEER
do not assume responsibility for the accuracy or completeness of information and data shown or indicated in the
Contract Documents with respect to Underground Facilities at or contiguous to the site.

6.02 Progress Payments; Retainage

any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the
delays, expense and difficulties involved in proving in a legal or arbitration preceding the actual loss suffered by
OWNER if the Work is not completed on time. Accordingly, instead of requiring any such proof, OWNER and
CONTRACTOR agree that as liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER
FIVE HUNDRED dollars ($500) for each calendar day that expires after the time specified in paragraph 4.02 for

STANDARD FORM OF AGREEMENT
BETWEEN OWNER AND CONTRACTOR

THIS AGREEMENT is dated as of the day of in the year 2016 by and between the
City of Nashua, New Hampshire (hereinafter called OWNER) and
and its successors, transferees and assignees together hereinafter called CONTRACTOR).

OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows:
ARTICLE 1 - WORK

1.01 CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents.
ARTICLE 2 - THE PROJECT

DIVISION 6
AGREEMENT

IN WITNESS WHEREOF, this instrument is executed

in

which shall be deemed an original,
this

ATTEST:

By:

(Principal) Secretary

(SEAL)

By:

Witness as to Principal

(Address)

ATTEST:

By

Witness as to Surety

(Address)

counterparts, each one of
(number)

day of , 20

Principal
BY
(Address)
(Surety)
BY

Attorney - in - Fact

(Address)

PROVIDED, that beneficiaries or claimants hereunder shall be limited to the subcontractors, and
persons, firms, and corporations having a direct contract with the PRINCIPAL or its
SUBCONTRACTORS.

CONSTRUCTION PAYMENT BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Address of Contractor)

a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

PROVIDED, FURTHER, that the said surety, for value received hereby stipulates and agrees
that no change, extension of time, alteration or addition to the terms of the contract or to WORK
to be performed thereunder or the specifications accompanying same shall in any way affect its
obligation on this BOND, and it does hereby waive notice of any such change, extension of time
alteration or addition to the terms of the contract or to the WORK or to the specifications.

CONSTRUCTION PERFORMANCE BOND

KNOW ALL MEN BY THESE PRESENTS: that

(Name of Contractor)

(Addtess of Contractor)

a , hereinafter called Principal,
(Corporation, Partnership or Individual)
and
(Name of Surety)
(Address of Surety)

hereinafter called Surety, are held and firmly bound unto

(Name of Owner)

(Address of Owner)

hereinafter called OWNER, in the total aggregate penal sum
of

Dollars, $
/ )