Part 3_City of Nashua, NH
Jackson Mills HPP
ili.
vi.
Vil.
viii.
xi.
xii.
Provide instruction and assistance during
installation.
Attend installation/assembly activities for portion of
the Equipment that will have an impact on
guaranteed values.
Carry out a check of proper installation and set up
of the Equipment.
Carry out a check of results of measured values.
Make daily submittals to the Technical Advice
Logbook for submittal, comments, approval and
signature of the Purchaser.
Attend co-ordination meetings organized by the
Purchaser at Project Site.
Respect comments of the Purchaser concerning
safety and fire protection at Project Site.
Maintain medical and travel insurance, which will
be provided by the Supplier at the Supplier's cost.
Abide by instructions of the Site Construction
Manager of the Purchaser at the Project Site in
accordance with the Contract.
Agree not to be entitled to comment on the
installation / assembly of the Equipment that is not
specified in the Contract and the Purchaser is not
entitled to demand such information or activities of
the Technical Advisor.
Be fluent in the English language.
b. Technical Advisor’s Authorization
The Techniical Advisor is authorized to do the following:
Request review of authorizations, licences and or
certificates of the Purchaser’s workers for activities
that directly relate to the installation of the
Suppliers Equipment, including but not limited to
welding certificate, if applicable, and authorisation
for testing.
Request immediate replacement of such person or
worker who does not have requested qualification,
experience, authorization or does not perform the
work in conformity with the instructions of the
Technical Advisor and in accordance with safety
and fire protection precautions.
Request replacement of mechanisms, _ tools,
hoisting equipment etc. that are not of the
requested quality or function.
Request an increase in the number of workers,
mechanisms etc. or extension of working time
(extra time).
vi.
vii.
viii.
Request the suspension and/or stoppage of any
work or withheld commencement and/or resume
the installation if a mechanism, tool or qualification
of the Purchaser’s workers do not correspond to
the requirements of the installation procedure or
safety, fire protection, environmental precautions or
if there are found shortcomings in Civil Works
Readiness or effecting the Warranty/performance
of the Equipment.
Request the Purchaser’s contractors to stop any
work of any assembly, installation and/or test
measurement that is not being carried out in
accordance with stipulated standards and/or
procedures given by the Supplier or according to
instructions of the Technical Advisor. Any disputes
will be resolved as quickly as possible by a meeting
of senior management from the Purchaser and the
Supplier shall be held not later than within 48 hours
of any dispute.
Request the Purchaser to shut down the turbine
unit for the reason of remedy of defects, faults etc.
for the requisite needful time.
All of the foregoing will be exercised in the
reasonable judgment of the Technical Advisor
Any possible delay, costs, damages or any other
consequences as a result of the Technical Advisor exercising
rights under clause b) of this article shall not be the Supplier's
responsibility provided the Technical Advisor exercised
reasonable judgment.
c. Purchaser’s Rights
The Purchaser has the following rights:
Request an immediate change of the Technical
Advisor, if the Purchaser comes to the conclusion that
the Technical Advisor does not fulfill duties according
to the Contract, and if after Purchaser informs the
Supplier in writing detailing the alleged breach and the
Supplier does not address and resolve the breach.
Provide written comments in the Technical Advice Log
Book.
Request, for extra payment, the following items:
- an increase in the number of Technical Advisors
- an extension of the stay of any Technical Advisor
- an extension of working time, overtime, work on
Saturday, Sunday or holiday, within local labor laws
and law of the country of the Supplier.
Demand compliance of safety and fire protection.
Demand attendance of the Technical Advisor at co-
ordinating meetings with the other Suppliers of the
Purchaser.
Demand the Technical Advisor conform to safety and
security requirements.
