Ink.
Application for Payment, that, to the best of the Architect's knowledge, information and belief, the Work has
progressed to the point indicated, the quality of the Work is in accordance with the Contract Documents, and that the
Contractor is entitled to payment in the amount certified. The foregoing representations are subject to (1) an evaluation
of the Work for conformance with the Contract Documents upon Substantial Completion, (2) results of subsequent
tests and inspections, (3) correction of minor deviations from the Contract Documents prior to completion, and (4)
specific qualifications expressed by the Architect.
§ 3.6.3.2 The issuance of a Certificate for Payment shall not be a representation that the Architect has (1) made
exhauslive or continuous on-site inspections to check the quality or quantity of the Work, (2) reviewed construction
means, methods, techniques, sequences or procedures, (3) reviewed copies of requisitions received from
Subcontractors and suppliers and other data requested by the Owner to substantiate the Contractor’s right to payment,
or (4) ascertained how or for what purpose the Contractor has used money previously paid on account of the Contract
Sum.
§ 3.6.3.3 The Architect shall maintain a record of the Applications and Certificates for Payment.
§ 3.6.4 Submittals
§ 3.6.4.1 The Architect shall review the Contractor's submittal schedule and shall not unreasonably delay or withhold
approval of the schedule. The Architect's action in reviewing submittals shall be taken m accordance with the
approved submittal schedule or, in the absence of an approved submittal schedule, with reasonable prompiness while
allowing sufficient time, in the Architect’s professional judgment, to permit adequate review.
§ 3.6.4.2 The Architect shall review and approve, or take other appropriate action upon, the Contractor's submittals
such as Shoup Drawings. Product Data and Samples, but only for the limited purpose of checking for conformance with
information given and the design concept expressed in the Contract Documents. Review of such submiitals is not for
the purpose of determining the accuracy and completeness of other information such as dimensions, quantities, and
installation or performance of equipment or systems, which are the Contractar’s responsibility. The Architect's review
shall not constitute approval of safety precautions or construction means, methods, techniques, sequences or
procedures. The Architect’s approval of a specific item shall not indicate approval of an assembly of which the item is
a component.
§ 3.6.4.3 If the Contract Documents specifically require the Contractor to provide professional design services or
certifications by a design professional related to systems, materials, or equipment, the Architect shall specify the
appropriate performance and design criteria thal such services must satisfy. The Architect shall review and take
appropriate action on Shop Drawings and other submittals related to the Work designed or certified by the
Contractor's design professional, provided the submittals bear such professional's seal and signature when submitied
to the Architect, The Architect's review shall be for the limited purpose of checking for conformance with information
given and the design concept expressed in the Contract Documents. The Architect shall be entitled to rely upon, and
shall not be responsible for, the adequacy and accuracy of the services, certifications, and approvals performed or
provided by such design professionals.
§ 3.6.4.4 Subject to Section 4.2, the Architect shall review and respond to requests for information about the Contract
Documents. The Architect shall set forth, in the Contract Documents, the requirements for requests for information.
Requests for information shall include, al a minimum, a detailed written statement thal indicates the specific Drawings
or Specifications in need of clarification and the nature of the clarification requested, The Architect’s response to such
requests shall be made in writing within any time limits agreed upon, or otherwise with reasonable promptness. If
appropriate, the Architect shall prepare and issue supplemental Drawings and Specifications in response to the
reguests for information.
§ 3.6.4.5 The Architect shall maintain a record of submittals and copies of submittals supplied by the Contractor in
accordance with the requirements of the Contract Documents.
§ 3.6.5 Changes in the Work
§ 3.6.5.1 The Architect may order minor changes in the Work that are consistent with the intent of the Contract
Documents and do not involve an adjustment in the Contract Sum or an extension of the Contract lime. Subject to
AIA Document B101™ — 2017. Copyright © 1974, 1978, 1987, 1997, 2007 and 2017 by The American Institute of Architects. All rights reserved. WARNING. This
AIA” Dacument is protectes by US. Copyright Law and international Treatles. Unauthorized rearoduction or distribution of this AIA’ Document, or any 44
portion af it, may result in severe civ and criminal penatties. and wilt be prosecuted to the maximum extent possitite urdar the faw This document was
praduced by AIA software at 11:12:42 ET on 04/02/2019 under Order No.0100024863 which expires an 12/13/2019, and is not for resale
User Notes: (4131096914)
