any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the
delays, expense and
difficulties involved in proving in a legal or arbitration proceeding the actual loss suffered by OWNER if the Work is
not completed on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as
liquidated damages for delay (but not as a penalty) CONTRACTOR shall pay OWNER ONE HUNDRED dollars
($100) for each calendar day that expires after the time specified in paragraph 4.02 for Substantial Completion until
the Work is substantially complete. After Substantial Completion, if CONTRACTOR shall neglect, refuse or fail to
complete the remaining Work within the time specified in paragraph 4.02 for completion and readiness for final
payment or any proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER TWO HUNDRED
dollars ($200) for calendar each day that expires after the time specified in paragraph 4.02 for completion and
readiness for final payment until the Work is completed and ready for final payment.
B. In the event that the CONTRACTOR fails to pay OWNER the specified liquidated damages amount
within thirty (30) days of CONTRACTOR's being notified of said damages, OWNER may deduct the amount of the
assessed liquidated damages from the final payment or retention withheld pursuant to Article 14 of the General
Conditions.
ARTICLE 5 - CONTRACT PRICE
5.01 Subject to additions and deductions by Change Order, the OWNER shall pay CONTRACTOR, in accordance
with the Contract Documents, the Contract Sum of:
($ )
The Contract Sum shall include all items and services necessary for the proper execution and completion of the Work
determined below:
A. for all Unit Price Work, an amount equal to the sum of the established Unit Price for each separately
identified item of Unit Price Work times the estimated quantity of that
item, as indicated in the attached Bid Schedule;
B. as provided in paragraph 11.03 of the General Conditions estimated quantities are not guaranteed, and
determinations of actual quantities and classification are to be made by ENGINEER as provided in paragraph 9.08 of
the General Conditions. Unit prices have been computed as provided in paragraph 11.03 of the General Conditions.
ARTICLE 6 - PAYMENT PROCEDURES
6.01 Submittal and Processing of Payments
A. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General
Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions.
B. CONTRACTOR shall submit Applications for Payment under this agreement directly to:
City of Nashua
Attn: Accounts Payable
PO Box 2019
Nashua, NH 03061-2019
Atten: Todd Welch
To facilitate the proper and timely payment of applications, the City of Nashua requires that all invoices contain
a valid PURCHASE ORDER NUMBER.
AG - 2 of 6
